LEGAL NOTICE
Advertisement for
Invitation for Bids
August 11, 2026
Notice is hereby given that sealed bids will be accepted by the Jefferson County Purchasing Department for Invitation for Bid (IFB 26-043/CG), Term
Contract for
Larvicidal Oil for
Jefferson County
Mosquito Control.
Specifications for this
project may be obtained from the Jefferson County website,
https://jeffersoncountytx.gov/Purchasing/ or by calling 409-835-8593.
Bids are to be sealed and addressed to the
Purchasing Agent with the bid number and name marked on the outside of the envelope or box. Bidders shall forward an original and one (1) copy of their bid to the address shown below. Jefferson County does not accept bids submitted
electronically. Late bids will be rejected as
non-responsive. Bids will be publicly opened and read aloud in the Jefferson
County Purchasing
Department (1st Floor,
Historic Courthouse) 1149 Pearl Street, Beaumont, Texas 77701, at the time and date below.
Bidders are invited to attend the sealed bid opening.
BID NAME: Term
Contract for Larvicidal Oil for Jefferson County
Mosquito Control
BID NUMBER: (IFB 26-043/CG)
DUE BY TIME/DATE: 11:00 am CT, Wednesday,
September 16, 2026
MAIL OR DELIVER TO: Jefferson County
Purchasing Department
1149 Pearl Street, 1st Floor
Beaumont, Texas 77701
Any questions relating to these bid requirements should be directed to Cindy Greene, Contract Specialist at 409-835-8593 or via email at: Cynthia.greene@jeffersoncountytx.gov. If no
response in 72 hours,
contact Deborah Clark, Purchasing Agent at 409-835-8593 or via email at deb.clark@jeffersoncountytx.gov.
Jefferson County
encourages Disadvantaged Business Enterprises (DBE/ACDBEs), Minority/Women Business Enterprises (M/WBEs), Small Business Concerns (HUBZone) and Veteran Heroes United In Business (VetHUB) to participate in the bidding process. Jefferson County does not discriminate on the basis of race, color,
national origin, sex, religion, age or disability in
employment, or the
provisions of services. Individuals requiring
special accommodations are requested to contact our office at least seven (7) days prior to the bid due date at 409-835-8593.
All interested firms are
invited to submit a bid in
accordance with the terms and
conditions stated in this bid.
Bidders are strongly
encouraged to carefully read the entire invitation, as failure to return and/or complete all required documentation will result in a response being
declared as non-responsive.
Deborah L. Clark,
Purchasing Agent
Jefferson County, Texas
CITY OF BEAUMONT
INVITATION TO BID
Bids will be received by the City of Beaumont,
Beaumont, Texas, until 2:00 P.M. (CT), THURSDAY, SEPTEMBER 3, 2026, and all bids will be opened and publicly read in the City Council
Chambers on that date for:
Construction of a Fuel Canopy for the Beaumont Municipal Transit System
Located at 550 Milam St., Beaumont, Texas 77701
A MANDATORY Pre-Bid meeting will be held on Wednesday, August 26, 2026, at 9:00 A.M. (CT), at the Beaumont
Municipal Transit Facility located at 550 Milam Street,
Beaumont, TX 77701.
Questions about the bid must be submitted by 5:00 P.M. (CT) on Friday, August 28, 2026. Answers to the questions may be provided through an
Addendum.
Bidding forms,
specifications and all
necessary information may be downloaded from the City’s e-bids platform at: https://beaumonttexas.ionwave.net/Login.aspx.
Bids must be submitted through the City’s e-bids
platform at: https://beaumonttexas.ionwave.net/Login.aspx.
Vendors must register to
submit a bid or proposal.
The City reserves the right to reject any or all bids, or to accept any bid or combination of bids deemed advantageous to it.
Please make reference to Bid Number: DF0826-15
Bid Closing Date:
SEPTEMBER 3, 2026
Tina Broussard
City Clerk
CITY OF BEAUMONT
INVITATION TO BIDDERS
Bids will be received by the City of Beaumont,
Beaumont, Texas, until 2:00 P.M. (CT),
THURSDAY,
SEPTEMBER 3, 2026 and all bids will be opened and
publicly read in the City Council
Chambers on that date for:
SIX (6) MONTH
CONTRACT FOR
ROAD MATERIALS –
ASPHALTIC CONCRETE
Questions about the bid must be submitted by 10:00 A.M. (CT) on
Monday, August 24, 2026. Answers to the
questions may be
provided through an Addendum.
Bid forms, specifications and all necessary information may be downloaded from the City’s e-bids platform at: https://beaumonttexas.ionwave.net/Login.aspx.
Bids must be submitted through the City’s e-bids platform at: https://beaumonttexas.ionwave.net/Login.aspx. Vendors must register to submit a bid or proposal.
The City reserves the right to reject any or all bids, or to accept any bid or combination of bids deemed advantageous to it.
Please make reference to Bid Number:MF0826-50
Bid Closing Date: SEPTEMBER 3, 2026
Tina Broussard
City Clerk
INVITATION TO BID
BID NO. WU1126-09
Sealed bids will be received online until 2:00 P.M. (CST), THURSDAY, SEPTEMBER 3, 2026, for furnishing all plans, administration, superintendence, labor, services, materials, tools, equipment, supplies, transportation, utilities, and all other items and facilities necessary therefore, as provided in the Contract Documents for the construction of:
CITY OF BEAUMONT
LOEB WELL No. 3 REHABILITATION AND PUMP REPLACEMENT
BID NO. WU1126-09
Bids will be opened and publicly read in the City Council Chambers at City Hall. The City reserves the right to reject any or all bids, or to accept any bid or combination of bids deemed advantageous to it.
Bidders must submit an original Bid Bond, Cashier’s Check, Certified Check or irrevocable Letter of Credit issued by a bank satisfactory to the Owner, payable without recourse to the order of the City of Beaumont in an amount not less than five (5) percent of the largest possible bid amount as a guaranty that the Bidder will enter into contract and execute bond and guaranty in the form provided within fourteen (14) calendar days after date of Notice of Award of the contract. Bids without the required financial security deposit will not be considered.
A MANDATORY Pre-Bid Conference will be held at 10:00 A.M., on WEDNESDAY, AUGUST 26, 2026, in-person at 1350 Langham Road, Beaumont, TX and virtually on Microsoft Teams. Attendees may join in-person, by internet, or phone call:
https://bit.ly/4woBhaX +1 903-405-2009 Passcode: 375 077 411#
Attendance at the Pre-bid meeting is a prerequisite to bidding. Prior to the pre-bid conference, interested bidders should obtain forms of proposal, contract, bond, and specifications. No one will be allowed to enter the pre-bid virtually or in-person if arrival is later than 5 minutes after the designated time. Calls for any technical difficulties must be made prior to the meeting.
Bidding forms, specifications and all necessary information may be downloaded from the City’s e-bids platform at: https://beaumonttexas.ionwave.net/Login.aspx and on civcastusa.com. There is no cost to view the plans, and printing can be done through the websites. Sets of hard copies of bidding Documents will not be sold.
Bids must be submitted through the City’s e-bids platform at: https://beaumonttexas.ionwave.net/Login.aspx. Vendors must register to submit a bid. Be advised, e-bids is the only option to submit bids to the City of Beaumont effective 8/1/23.
Please make sure to reference Bid Number: WU1126-09
CITY OF BEAUMONT, TEXAS, OWNER
By: Tina Broussard
City Clerk
NOTICE TO BIDDERS
REQUEST FOR
PROPOSAL (RFP)
810 Medical Office
Building Security
Improvements
Issuing Entity Baptist
Hospitals of Southeast Texas
Submission Due Date August 20, 2026
Sole Point of Contact Reggie Wasson,
Safety Officer, rwasson@bhset.net, 409-828-8112
Baptist Hospitals of
Southeast Texas is
requesting proposals from qualified vendors to
provide and install security improvements for the 810 Medical Office Building. The project includes
additions to video
surveillance, access
control, panic alarm
capability, electrical
infrastructure, and associated roof/parapet support work required for proper installation and commissioning.
PROJECT PURPOSE AND BACKGROUND
The 810 Medical Office Building assessment identified the IT data closets, entry points, hallways, and parking lot as areas vulnerable to potential threats including assault, theft, burglary, and other security incidents. The requested improvements are intended to increase monitoring, strengthen controlled access, support emergency notification, and improve overall security coverage for the facility.
BASE SCOPE OF WORK
Video Surveillance: furnish, install, configure, license, and commission interior and exterior IP camera surveillance equipment, including required server/NVR equipment, camera switching, cabling, UPS, monitor, and video analytics/software licensing as applicable.
Electrical Work: include power required for camera junction boxes on four parking lot poles, quad receptacles in two data rooms, and core drilling with sleeves in two data rooms.
Roof/Parapet Work: include wall-mount bracket installation at roof/parapet camera locations, liquid flashing over brackets, and pipe box work for electrical routing where required.
Project Closeout: include configuration, commissioning, testing, as-built documentation, training/turnover, and warranty/support information.
CONTRACTOR QUALIFICATION REQUIREMENTS
Respondents performing security system work shall hold all licenses required for the proposed scope, including a current Texas security license issued by the Texas Department of Public Safety where applicable.
Respondents performing electrical work shall hold all electrical licenses required by the State of Texas.
Respondents shall identify manufacturer certifications, dealer authorizations, and integration partner credentials
relevant to the proposed video surveillance, access control, panic alarm, and related systems.
Respondents shall be capable of coordinating work in an active healthcare/medical office environment and shall comply with all owner, hospital facility, state, local, and federal requirements applicable to the work.
Respondents shall provide labor rate sheets for all applicable skill sets, including standard, overtime, weekend,
holiday, travel, and material markup rates.
PROPOSAL SUBMISSION REQUIREMENTS
Narrative proposal describing the respondent’s approach to the full project scope.
Itemized pricing by major scope category: video surveillance, access control, panic buttons, electrical work,
roof/parapet support work, software/licensing, project management, and closeout/training.
Proposed equipment list including quantities, model numbers, licensing assumptions, substitutions, and exclusions.
Project schedule showing procurement, installation, configuration, commissioning, and turnover milestones.
Description of after-hours availability, response time, support model, warranty terms, and escalation contacts.
Copies of applicable licenses, certifications, insurance, bonding capacity if required, and any subcontractor
qualifications.
Hospital or healthcare project references completed within the last five years, if available.
List of assumptions, exclusions, owner responsibilities, and required site access conditions.
FEDERALLY FUNDED SELECTION CRITERIA
Evaluation Category
Integrated video surveillance, access control, and panic alarm proposal
Weight Requested Contents
35% Technical approach, equipment list, certifications, licensing, rate sheets, material markup, and commissioning plan.
Evaluation Category
Electrical and roof/parapet support proposal
Weight Requested Contents
25% Electrical licensing, power/core-drill scope, roof/parapet support methods, waterproofing approach, rate sheets, and bonding information if required.
Evaluation Category
Proposed completion time and support availability
Weight Requested Contents
20% Project timeline, procurement lead times, after-hours support availability, response times, and turnover plan.
Evaluation Category
Past performance in hospital or healthcare setting
Weight Requested Contents
15% Relevant healthcare, medical office, critical infrastructure, or occupied-facility projects completed within the last five years.
Evaluation Category
Past work experience with Baptist Hospitals of Southeast Texas
Weight Requested Contents
5% Prior work history, familiarity with owner standards, and demonstrated ability to coordinate with facility stakeholders.
GENERAL CONDITIONS
Failure to apprise oneself of hospital, facility, state, local, federal, licensing, code, safety, and grant-related requirements will not excuse any bidder from compliance with applicable requirements.
All work shall be coordinated with facility representatives to minimize disruption to occupied areas and maintain safe
access to patient, visitor, staff, and tenant spaces.
The owner reserves the right to reject any or all bids, waive informalities, request clarification, negotiate scope, and
request new bids for the whole or any portion of the work.
The owner may reject incomplete proposals, proposals that do not demonstrate required licensing or qualifications, and proposals that fail to address the requested scope and submission requirements.
This notice is intended as a bid solicitation summary. The final RFP package, drawings, site conditions, and owner-issued addenda shall govern the work
BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF GROVES:
SECTION 1: - That the proposed budget for the fiscal year October 1, 2026
through September 30, 2027 of the City of Groves has been duly filed with the City Council of said City.
SECTION 2: - That proper public notice of the public hearings of such budget was made stating the place, date, and hour of such hearings, which were held in the Groves City Council
Chamber in the City of Groves, Texas, 3947 Lincoln Avenue, on the 3 rd day of August, 2026, at 5:00
p.m., as required by law.
SECTION 3: - That the estimated amount of revenues to be made available from all
sources for the fiscal year October 1, 2026, through September 30, 2027, is $44,171,972.
SECTION 4: - That the sum of $44,171,972 is appropriated and shall be disbursed for the following purposes and uses:
General Government – Mayor & City Council $ 72,929
General Government – City Manager $ 741,803
General Government – Human Resources
$ 319,346
General Government – Finance $ 619,921
Municipal Court $ 169,385
Library $ 416,082
Parks & Recreation $ 447,825
Police $ 4,914,219
Fire $ 2,338,220
Animal Control $ 105,405
Animal Shelter $ 43,000
Emergency Management $ 20,580
Inspections & Permits $ 481,577
Public Works & Administration $ 481,569
Garage $ 318,576
Streets $ 1,764,210
City Property Maintenance $ 529,000
Special Items – General Fund $ 476,253
Solid Waste $ 1,542,446
Special Items – Solid Waste $ 475,054
Water Plant $ 1,482,833
Wastewater Plant ... $ 1,495,257
Customer Service $ 278,888
Water Distribution $ 1,246,838
Special Items – Systems Fund $ 18,254,684
General Obligation Debt Service $ 2,834,572
Special Items – Sales Tax Fund $ 2,301,500
TOTAL $ 44,171,972
LEGAL NOTICE
Advertisement for Invitation for Bids
August 6, 2026
Notice is hereby given that sealed bids will be accepted by Jefferson County Drainage District No. 6 for
a (IFB 26-022/SC) Term Contract for Trash Removal Services for Jefferson County Drainage District No.
6. Specifications for this project may be obtained from the Jefferson County Drainage District No. 6
Webpage https://dd6.org/departments/purchasing/notices-for-bid/
Bids are to be sealed and addressed to Jefferson County Drainage District No. 6 and marked “Administrative Sealed Bid” with (IFB 26-022/SC) Term Contract for Trash Removal Services, for Jefferson County Drainage District No. 6” on the outside of the envelope. Bidders shall forward an original and two (2) copies of their bid to the address shown below. The District does not accept bids submitted electronically. Late bids will be rejected as non-responsive.
Administrative bids will be
publicly opened and read aloud in the Jefferson County Drainage District No. 6 boardroom at the time and date below. Bidders are invited to attend the bid opening.
BID NAME: Term Contract for Trash Removal Services
BID NUMBER: IFB 26-022/SC
DUE DATE/TIME: 2:00 PM, August 20, 2026
MAIL OR DELIVER TO: Jefferson County Drainage District No. 6
6550 Walden Rd.
Beaumont, Texas 77707
Any questions relating to these requirements should be directed to Shelby Clodfelter, Buyer/Contract Administrator II, at 409-842-1818 or sclodfelter@dd6.org.
Jefferson County Drainage District No. 6 reserves the right to accept or reject any or all bids, to waive technicalities and to take whatever action is in the best interest of the District.
All interested vendors are invited to submit a bid in accordance with the terms and conditions stated in
this bid.
RESPONDENTS ARE STRONGLY ENCOURAGED TO CAREFULLY READ THE ENTIRE INVITATION.
Karen K. Johnson, MBA, CTCD, CTCM Chief Business Officer Jefferson County Drainage District No. 6, Texas
LEGAL NOTICE
Advertisement for
Request for Proposal
August 6, 2026
Notice is hereby given that sealed proposals will be accepted by Jefferson County Drainage District No.
6’s (District) Purchasing Department for RFP 26-026/SC, Five (5) -Year Update to the Jefferson County Drainage District No. 6 Hazard Mitigation Plan. Specifications for this proposal may be obtained
from the District’s website, https://dd6.org/departments/purchasing/notices-for-bid/.
Proposals are to be sealed and addressed to the Chief Business Officer with the proposal number and name marked on the outside of the envelope or box. Proposers shall forward an original and four (4) hard copies of their proposal to the address shown below. Late proposals will be rejected as non-responsive. Proposals will be publicly opened and only the firm name will be read aloud in the Jefferson
County Drainage District No. 6 Board Room at the time and date below. Proposals shall be opened in a
manner that avoids disclosure of the contents to competing Proposers and maintains the confidentiality of the proposals during negotiations. Proposals will be open for public inspection after the award of the contract, except for trade secrets and confidential information. Proposers are invited to attend the sealed proposal opening.
PROPOSAL NAME: Five (5) -Year Update to the Jefferson County Drainage District No. 6 Hazard Mitigation Plan
PROPOSAL NO: RFP 26-026/SC
DUE DATE/TIME: 2:00 PM CDT, August 27, 2026
MAIL OR DELIVER TO: Jefferson County Drainage District No. 6 Purchasing Department
6550 Walden Road
Beaumont, Texas 77707
Any questions relating to these requirements should be directed to Shelby Clodfelter, CTCD, Buyer/Contract Administrator II, in writing to sclodfelter@dd6.org. by August 24, 2026, by 1:00 PM, CST.
Jefferson County Drainage District No. 6 reserves the right to accept or reject any or all bids, to waive
technicalities and to take whatever action is in the best interest of the District.
All interested vendors are invited to submit a proposal in accordance with the terms and conditions stated in this bid. All contractors/subcontractors whose System for Award Management (SAM.gov) registration is not active or that are debarred, suspended or otherwise excluded from or ineligible for participation in federal assistance programs may not undertake any activity in part or in full under this project.
RESPONDENTS ARE STRONGLY ENCOURAGED TO CAREFULLY READ THE ENTIRE INVITATION.
Karen K. Johnson, MBA, CTCD, CTCM Chief Business Officer Jefferson County Drainage District No. 6, Texas
LEGAL NOTICE
Advertisement for
Invitation for Bids
August 6, 2026
Notice is hereby given that sealed bids will be accepted by the Jefferson County
Drainage District No. 6 Purchasing Department for: (IFB 26-024/SC) Term Contract for Heavy Materials. for Jefferson County Drainage District No. 6. Specifications for this
project may be obtained from the Jefferson County Drainage District No. 6 webpage,
https://dd6.org/departments/purchasing/notices-for-bid
Bids are to be sealed and addressed to the Purchasing Department with the bid number and name marked on the outside of the envelope. Bidders shall forward an original and
three (3) copies of their bid to the address shown below. Jefferson County Drainage District No. 6 does not accept bids submitted electronically. Late bids will be rejected as non-responsive. Bids will be publicly opened and read aloud in the Jefferson County Drainage District No. 6 Boardroom at the time and date below. Bidders are invited to attend the
sealed bid opening.
BID NAME: Term Contract Heavy Materials
BID NO: IFB 26-024/SC
DUE DATE: 2:00 PM, August 20, 2026
MAIL OR DELIVER TO: Jefferson County Drainage District No. 6
Purchasing Department
6550 Walden Rd.
Beaumont, Texas 77707
Any questions relating to these requirements should be directed to Shelby Clodfelter, Buyer/Contract Administrator II, at 409-842-1818 or sclodfelter@dd6.org.
Jefferson County Drainage District No. 6 reserves the right to accept or reject any or all bids, to waive technicalities and to take whatever action is in the best interest of the District.
All interested vendors are invited to submit a bid in accordance with the terms and conditions stated in this bid.
RESPONDENTS ARE STRONGLY ENCOURAGED TO CAREFULLY READ THE ENTIRE INVITATION.
Karen K. Johnson, MBA, CTCD, CTCM Chief Business Officer Jefferson County Drainage District No. 6, Texas
LEGAL NOTICE
Advertisement of
Invitation for
Qualifications
August 6, 2026
Notice is hereby given that sealed bids will be accepted by Jefferson County Drainage District No. 6 for (RFQ 26-019/KKJ)
Professional Construction Inspection and Materials Testing Services for the Corley Diversion Project. Specifications for this
project may be obtained from the Jefferson County Drainage District No. 6 webpage
https://dd6.org/departments/purchasing/notices-for-bid/.
This project will be federally funded by the U.S. Housing and Urban Development (HUD) Department through the Texas General Land Office (GLO) via contract #24-065-004-E161. Firms shall comply with regulations governing the CDBG
Regional Mitigation Program (Regulation 24 CFR 570). Applicable requirements include but are not limited to compliance with the Davis-Bacon and Related Acts, Fair Labor Standards, Equal Employment Opportunity, Affirmative Action, Section
3 of the HUD Act of 1968, and contracting with small, minority, and disadvantaged firms, as detailed in the project manual. In addition, the successful Firms must ensure that employees and applicants for employment are not discriminated against
because of race, color, religion, sex, sexual identity, gender identity, or national origin.
All interested firms shall obtain a “Request for Qualifications” packet from the Jefferson County Drainage District No. 6 web site at https://dd6.org/departments/purchasing/notices-for-bid/ or request a copy via email to kjohnson@dd6.org .
All responses shall be submitted with an original and three (3) copies of their qualifications to the address shown below. The District does not accept qualifications electronically. Late submittals will be rejected as non-responsive. Qualifications will be publicly opened and only the names of responding firms will be read aloud at the Jefferson County Drainage District No. 6 facilities at the time and date below. Firms are invited to attend the sealed opening.
All qualifications shall be submitted to the Purchasing Department in a sealed envelope marked:
Request NAME: Professional Construction Inspection and Materials Testing Services
Request NO: RFQ 26-019/ KKJ
DUE DATE/TIME: 2:00 PM, August 27, 2026
MAIL OR DELIVER TO: Jefferson County Drainage District No. 6
6550 Walden Rd.
Beaumont, Texas 77707
Any questions relating to these requirements should be directed to Karen K. Johnson, MBA, CTCD, CTCM Chief Business Officer, in writing to kjohnson@dd6.org. by Friday, August 21, 2026 by 1:00 PM, CST. Jefferson County Drainage District No. 6 reserves the right to accept or reject any or all bids, to waive technicalities and to take whatever action is in the best interest of the District.
All interested vendors are invited to submit a bid in accordance with the terms and conditions stated in this bid. All contractors/subcontractors whose System for Award Management (SAM.gov) registration is not active or that are debarred,
suspended or otherwise excluded from or ineligible for participation in federal assistance programs may not undertake any
activity in part or in full under this project.
Karen K. Johnson, MBA, CTCD, CTCM Chief Business Officer Jefferson County Drainage District No. 6, Texas
ADVERTISEMENT FOR BIDS
Sealed lump sum BIDS will be received by the Board of Commissioners of the Port of
Beaumont Navigation District of Jefferson County, Texas at the Port of Beaumont Administrative Office, 1225 Main Street, Beaumont, Texas 77701 until 2:00 p.m. local time, Beaumont, Texas on September 2, 2026 for the Port of Beaumont Terminal Connectivity & Improvement Project, at which time the BIDS will be opened publicly and read aloud. Bidders or interested parties can participate in hearing the bids read aloud via teleconference. Any BIDS
received after closing time will be returned unopened.
Each BID must be submitted in a sealed envelope, addressed to Mr. Brandon Bergeron, Director of Engineering, at the Port of Beaumont, P.O. Drawer 2297, Beaumont, Texas 77704. Each sealed envelope containing a BID must be plainly marked on the outside as BID for Port of Beaumont Terminal Connectivity & Improvement Project and the envelope should bear on the outside the name of the BIDDER, its address, and its contractor’s license number (if applicable). If forwarded by overnight or express mail, the sealed envelope containing the BID must be enclosed in another envelope addressed to Mr. Brandon Bergeron, Port of Beaumont, 1225 Main Street, Beaumont, Texas 77701. For purposes of express mail forms, the Port’s telephone number is (409) 835-5367. BIDS received electronically, or by telefacsimile, will not be accepted.
A pre-bid conference will be held at the Port of Beaumont Administrative Office, 1225 Main Street, Beaumont, Texas. The pre-bid conference will be held at 2:00 p.m. local time, Beaumont, Texas on August 18, 2026. ATTENDANCE AT THE PRE-BID CONFERENCE IS MANDATORY AND IS A PREREQUISITE TO A BIDDER BEING AWARDED THE BID.
TWIC Cards are required for all contractor and subcontractor employees that enter the Port of Beaumont. The contractor shall be responsible for obtaining these cards and the cost of these cards shall be included in the bid price. The Contractor will be responsible for obtaining training (performed by Port Authority Police) for their supervisors or designated employees to be certified as TWIC escorts to accompany any non-TWIC employees, subcontractors, vendors, etc as per 33 CFR 101.
Each BID must include a BID BOND (certified check, cashier’s check or BIDDER’S bond), equal to five percent (5%) of the amount of the BID. BID BONDS of unsuccessful BIDDERS will be returned.
Project includes, but is not necessarily limited to, the following items in accordance with the TECHNICAL SPECIFICATIONS and PROJECT DRAWINGS:
Mobilization/Demobilization
SWPPP & Site Preparation
Civil Demolition
Drainage Improvements
Subgrade Preparation
Full-Depth Repair of Pavement
Mill/Overlay Asphalt Pavement
Rail Improvements
Fencing & Gates
Signage and Striping
The BID Documents may be examined without charge at the Port of Beaumont’s address listed above during normal working hours.
The BID Documents will also be available at the Port’s website for download at the following website address: https://www.portofbeaumont.com/business-with-the-port/bids/.
In accordance with Texas State law, including Local Government Code Chapter 176, each BIDDER MUST COMPLETE AND SUBMIT WITH THEIR BID A COPY OF THE VENDOR’S CONFLICT OF INTEREST QUESTIONNAIRE CONTAINED IN EXHIBIT “O”.
The Port of Beaumont reserves the right to reject any or all BIDS and to waive
formalities in BIDDING. In case of ambiguity or lack of clearness in stating the price in any BID, the Port of Beaumont reserves the right to consider the most advantageous BID thereof, or reject the BID.
HUD 2025
CONSOLIDATED ANNUAL PERFORMANCE AND EVALUATION REPORT
In compliance with regulations of the U. S. Department of Housing and Urban Development (HUD) governing the City of Beaumont Community Development Block Grant Program and the HOME Investment Partnership Program. The City of Beaumont will hold a public hearing to receive comments on its Consolidated Annual Performance and Evaluation Report (CAPER). The purpose of this report is to present to HUD and to the citizens of Beaumont a summary of relevant information regarding the expenditure of Federal grant funds from HUD during the past reporting period of July 1, 2025 through June 30, 2026.
Copies of the CAPER in draft form will be made available on the city website at www.beaumonttexas.gov and at the Beaumont City Hall, Community Development and Housing department located at 801 Main Street, Beaumont from 8:00 a.m. to 5:00 p.m., Monday through Friday, during normal business hours.
Comments on this report will be solicited at the Annual Performance and Assessment Public Hearing scheduled for Tuesday, September 8, 2026 at 1:30 p.m., at the City of Beaumont, City Council meeting.
All citizens are encouraged to attend this public hearing and present their views to the city council. If you cannot attend in person, written comments may be submitted and will be accepted by the City until this public hearing is concluded.
The City of Beaumont Affirmatively Furthers Fair Housing and is an Equal Opportunity Employer.
Persons with disabilities, who plan to attend this meeting and may need auxiliary aids or services, are requested to contact Jackie Gunner, prior to the meeting at (409) 880-3782.
Persons who need language translation services, who plan to attend this meeting, are requested to contact Cindy Aviles, prior to the meeting, at (409) 880-3762.
Written comments are also welcomed and must be received in the office of Community Development, 801 Main Street, Beaumont, Texas, 77701 by Monday, September 15, 2026 at 5:00 p.m. All public comments regarding the City’s performance under these grant programs and regarding the proposed changes to the Consolidated Annual Performance and Evaluation Report (CAPER) will be included as Appendices to the report. The final report as proposed will be submitted to HUD on or before Friday, September 18, 2026.
The report contains accomplishment data, number of persons assisted, Community Development targeted areas, the HOME Investment Partnership Program and the Community Development Block Grant 2025 Program Year expenditures which ran from July 1, 2025 through June 30, 2026.
For more information or questions regarding this performance report, please contact Cheryl Robinson, Grants Coordinator, City of Beaumont, 801 Main Street, Beaumont, Texas 77701, 409-880-4749, or by email at Cheryl.Robinson@Beaumonttexas.gov.
Water District
Notice of Public Hearing on Tax Rate
The Hardin County WCID #1 will hold a public hearing on a proposed tax rate for the tax year 2026 on
September 14, 2026 at 6:30 PM at Emergency Services District No.5 Station, 333 Commercial Drive, Sour
Lake, TX 77659. Your individual taxes may increase at a greater or lesser rate, or even decrease, depending
on the tax rate that is adopted and on the change in the taxable value of your property in relation to the change in taxable value of all other property. The change in the taxable value of your property in relation to the change in the taxable value of all other property determines the distribution of the tax burden among all
property owners.
Visit Texas.gov/PropertyTaxes
to find a link to your local property tax database on which you can easily
access information regarding your property taxes, including information about proposed tax rates and scheduled public hearings of each entity that taxes your property.
For the proposal: Buddy Hughes, Ben Fox,
Allen Davis, Wayne Turk
Against the proposal:
Present and not voting:
Absent: Jack Maddox
The following table compares taxes on an average residence homestead in this taxing unit last year to taxes
proposed on the average residence homestead this year.
Last Year
Total tax rate (per $100 of value)
$0.180380/$100
Adopted
This Year
$0.186067/$100
Proposed
Difference in rates per $100 of value $0.005687
Percentage increase/decrease in rates(+/-) 3.15%
Average residence homestead appraised value
Last Year
$305,496
This Year
$303,132
General homestead exemptions available
(excluding 65 years of age or older or disabled
person’s exemptions)
Last Year
$0
This Year
$0
Average residence homestead taxable value
Last Year
$305,496
This Year
$303,132
Tax on average residence homestead
Last Year
$551.05
This Year
$564.03
Annual increase/decrease in taxes if proposed tax rate is adopted (+/-) $12.98
and percentage of increase (+/-) 2.36%
If the proposed combined debt service, operation and maintenance, and contract tax rate requires or authorizes an election to approve or reduce the tax rate the Board of Directors of Hardin County WCID #1 proposes to use the tax increase for the purpose of the operation of WCID #1.
NOTICE OF VOTE
ON TAX RATE
If the district adopts a combined debt service, operation and maintenance and contract tax rate that would result in the taxes on the average residence homestead increasing by more than 3.5 percent, an election must be held to determine whether to approve the operation and maintenance tax rate under Section 49.23602, Water Code. An election is not required if the adopted tax rate is less than or equal to the voter-approval tax
rate.
The 86th Texas Legislature modified the manner in which the voter-approval tax rate is calculated to
limit the rate of growth of property taxes in the state.
NOTICE OF PUBLIC SALE
Pursuant to Chapter 59, Texas Property Code, EZ Secure Storage will hold an online public auction of property being sold to satisfy a landlord’s lien. Sale to be held online at www.StorageTreasures.com. Facility location at 1715 Hwy 327 W, Silsbee, TX 77656. Bidding will open on 8/21/26 at 10 AM and conclude on 8/28/26 at 10 AM. Cleaning deposit required, payments must be made electronically, and items must be removed within 60 hours of auction end. Seller reserves the right to withdraw the property at any time before the sale. Unit items sold as-is to the highest bidder. Property includes the unit contents of the following tenants: Devon J Wise, Chaniqua Lattice Sells, Alicia Gaines, Renedia Anderson, Yasmine McSpadden. Contents include personal items, household goods, tools, toys, books, art, clothing, electronics and sporting goods.
NOTICE OF PUBLIC SALE
Pursuant to Chapter 59, Texas Property Code, EZ Secure Storage will hold an online public auction of property being sold to satisfy a landlord’s lien. Sale to be held online at www.StorageTreasures.com. Facility location at 5440 Old Dowlen Rd, Beaumont, TX 77706. Bidding will open on 8/21/26 at 10 AM and conclude on 8/28/26 at 10 AM. Cleaning deposit required, payments must be made electronically, and items must be removed within 60 hours of auction end. Seller reserves the right to withdraw the property at any time before the sale. Unit items sold as-is to the highest bidder. Property includes the unit contents of the following tenants: DJ Pena, Savannah Willis, Kierra Bronson, Jamie Howard, Courtney Goins, Vanity Mattox, Donna M Hankamer, Kimyunta Gilliam, LaToya Anderson. Contents include personal items, household goods, tools, furniture, toys, books, art, clothing, electronics and sporting goods.
HOUSE FOR SALE
2350 S. 8TH Street
Beaumont, TX 77701
3-1- 58K
“AS IS”
Pat Gibbs, Broker
(409) 466-1879
CENTRAL MAXI
STORAGE
NOTICE OF PUBLIC SALE
Notice of Public Sale of Property to satisfy a landlord’s lien. Sale will be held at Central Maxi Storage 885 Ridgewood Dr. Port Neches, Texas 77651 on August 22nd,2026 at 1:15 PM. Clean up and card deposit of $45.00 is required. Seller reserves the right to withdraw the property at any time before the sale. Unit items will be sold for cash to the highest bidder. Property includes the contents of spaces of the following tenants:
Elizabeth Hernadez
Shenequa Jones
Barbara Wall
Mark Papania
Delia Minter
Van Thompson
Hermela Garnica
Orelia Normand
Ray Ramirez
Karla Galvan
Jairo Quinones
CUBESMART
SELF STORAGE
NOTICE OF PUBLIC SALE: Self-storage Cube contents of the following customers containing
household and other goods will be sold for cash by CubeSmart Asset Management, LLC as
Agent for Owner to satisfy a lien on August.28,2026 at approx. 12:00 P.M. at
www.storagetreasures.com
CubeSmart 4330: 150 Morgan Dr, Vidor, TX 77662
Corey Stone
Hank Wipf
Isabella Fontenot
Wyatt Lummus
Kevin Caswell
CITATION BY
PUBLICATION – DIVORCE W/ CHILDREN
THE STATE OF TEXAS
Cause No. 26-FD-0761
COUNTY COURT AT LAW NO. 1 OF GALVESTON COUNTY, TEXAS
IN THE MATTER OF THE MARRIAGE OF: MARTHA FLORE BAZORIA
AND
AGUSTIN JAMIE BAZORIA - RODRIGUEZ
To: AGUSTIN JAMIE BAZORIA - RODRIGUEZ
Greetings
NOTICE TO RESPONDENT: You have been sued. You may employ an attorney. If you or your attorney do not file a written answer with the clerk who issued this citation by 10:00 a.m. on the Monday next following the expiration of twenty days from the date you were served this citation and petition/motion, a default judgment may be taken against you. In addition, to filing a written answer with the clerk, you may be required to make initial disclosures to the other parties to this suit. These disclosures generally must be made no later than 30 days after you file your answer with the clerk. Find out more at TexasLawHelp.org.
The petition of MARTHA FLORE BAZORIA Petitioner, was filed in the County Court at Law No. 1 of Galveston County, Texas on the 24th day of April, 2026, against AGUSTIN JAMIE BAZORIA – RODRIGUEZ, Respondent(s), numbered 26-FD-0761 and entitled “IN THE MATTER OF THE MATTER OF MARTHA FLORES BAZORIA AND AGUSTIN JAIME BAZORIA RODRIGUEZ” The suit requests: Original Petition for Divorce as is more fully shown by Petitioner on file in this Suit.
The date and place of birth of the child (children) who is (are) the subject of the suit:
DOB – 04/25/2015, Birthplace - Galveston Texas
“The court has authority in this suit to enter any judgment or decree dissolving and providing for the division of the property, furthermore the Court has authority in this suit to render an order in the child ‘s (children’s) interest, including the termination of the parent-child relationship, the determination of paternity and the appointment of a conservator with authority to consent to the child ‘s (children’s) adoption, all of which will be binding on you.”
The officer executing this process shall promptly execute the same according to law, and make due process as the law directs.
ISSUED and GIVEN under my hand and the seal of said court, at Galveston, Texas, 5th day of August, 2026.
JOHN D. KINARD,
DISTRICT CLERK
GALVESTON COUNTY, TEXAS
BY /s/ Angelo Marenco, Deputy
THE STATE OF TEXAS
No. 25DCCV1219
KW VENTURES, INC.
VS.
IVORY C. LOWE
CITATION BY
PUBLICATION –
IVORY C . LOWE
172ND DISTRICT COURT
JEFFERSON COUNTY,
TEXAS
To: Ivory C. Lowe
3043 KEYSTONE AVENUE
PORT ARTHUR, TEXAS 77640
DEFENDANT:
SEE ATTACHED
NOTICE: You have been sued. You may employ an attorney. If you or your attorney do not file a written answer with the clerk who issued this citation by 10:00 a.m. on the Monday next following the expiration of 42 days after the date this citation was issued, a default judgment may be taken against you, the answer date being at or before 10 o’clock A.M. on Monday, September 7, 2026. In addition to filing a written answer with the clerk, you may be required to make initial disclosures to the other parties of this suit. These disclosures generally must be made no later than 30 days after you file your answer with the clerk. Find out more at TexasLawHelp.org Said answer may be filed by mailing same to: District Clerk’s Office, 1085 Pearl, Room 203, Beaumont, TX 77701, or by bringing it to the office. The case is presently pending before the 172nd District Court District Court of Jefferson County sitting in Beaumont, Texas, and was filed on the 15th day of June 2026. It bears cause number 26DCCV1219 and is styled:
KW VENTURES, INC.
vs.
IVORY C. LOWE
The name and address of the attorney for plaintiff (or plaintiff if pro se) is:
ALEX WEATHERFORD
1400 BROADFIELD BOULEVARD STE 105
HOUSTON, TX. 77084
The nature of the demands of said plaintiff is shown by a true and correct copy of Plaintiff’s Brief accompanying this citation and made a part thereof.
Issued under my hand and the seal of said court, at Beaumont, Texas, this the 24th day of June, 2026.
JAMIE SMITH,
DISTRICT CLERK
JEFFERSON COUNTY,
TEXAS
BY Erin Harper,
Erin Harper, Deputy
THE STATE OF TEXAS
CITATION BY
PUBLICATION
TO: UNKNOWN HEIRS
OF SILAS MCCRAY
ROGERS, DECEASED
DEFENDANT(S)
GREETINGS:
You are hereby commanded to appear before the Honorable Probate County Court of Jefferson County, Texas, at the Courthouse of said County in the City of Beaumont, Jefferson County, Texas, at or before 10 o’clock a.m. of the first Monday after the expiration of ten (10) days from the date of issuance thereof, same being Monday, 08/17/2026 then and there to answer the proceeding to declare heirship filed by Darrell Lynn Rogers, Applicant, in said Court on 08/04/2026, in Cause No. 26CPR1078, styled,
IN THE ESTATE OF SILAS MCCRAY ROGERS, DECEASED
A brief statement of the nature of the petition is as follows, to-wit:
DETERMINE THE HEIRS AND THEIR RESPECTIVE SHARES & INTERESTS UNDER THE LAWS OF THIS STATE OR IN THE TRUST, AS APPLICABLE IN THE DECEDENT’S ESTATE
as is more fully shown by the petition on file in this cause.
The officer executing this process shall promptly execute the same according to law, and make due return as the law directs. If this citation is not served within (90) days after day of issuance, it shall be returned unserved.
Issued and given under my hand and seal of said Court at Beaumont, Texas, on this the 4th of August, 2026
Roxanne Acosta-Hellberg, County Clerk
Jefferson County, Texas
By Suzette Johnson, Deputy
SUZETTE JOHNSON
THE STATE OF TEXAS
CITATION BY
PUBLICATION
TO: UNKNOWN HEIRS
OF MICHAEL ELLIOTT LEDFORD, DECEASED
DEFENDANT(S)
GREETINGS:
You are hereby commanded to appear before the Honorable Probate County Court of Jefferson County, Texas, at the Courthouse of said County in the City of Beaumont, Jefferson County, Texas, at or before 10 o’clock a.m. of the first Monday after the expiration of ten (10) days from the date of issuance thereof, same being Monday, 08/17/2026 then and there to answer the proceeding to declare heirship filed by Cara Ledford, Applicant, in said Court on 08/04/2026, in Cause No. 26CPR1079, styled,
IN THE ESTATE OF
MICHAEL ELLIOTT
LEDFORD, DECEASED
A brief statement of the nature of the petition is as follows, to-wit:
DETERMINE THE HEIRS AND THEIR RESPECTIVE SHARES & INTERESTS UNDER THE LAWS OF THIS STATE OR IN THE TRUST, AS APPLICABLE IN THE DECEDENT’S ESTATE
as is more fully shown by the petition on file in this cause.
The officer executing this process shall promptly execute the same according to law, and make due return as the law directs. If this citation is not served within (90) days after day of issuance, it shall be returned unserved.
Issued and given under my hand and seal of said Court at Beaumont, Texas, on this the 4th of August, 2026
Roxanne Acosta-Hellberg, County Clerk
Jefferson County, Texas
By Suzette Johnson, Deputy
SUZETTE JOHNSON
THE STATE OF TEXAS
NO. 25DCCV1330
KEVIN C. MITCHELL
VS.
CIA TRANSPORT, INC.,
ET AL
CITATION BY
PUBLICATION-
PERSON
58th DISTRICT COURT
JEFFERSON COUNTY,
TEXAS
To: Mirim Freight, Inc. BY SERVING THE REGISTERED AGENT: ROMAN A ZENCHENKO
DEFENDANT:
SEE ATTACHED
NOTICE: You have been sued. You may employ an attorney. If you or your attorney do not file a written answer with the clerk who issued this citation by 10:00 a.m. on the Monday next following the expiration of 42 days after the date this citation was issued, a default judgment may be taken against you, the answer date being at or before 10 o’clock A.M. on Monday, September 21, 2026. In addition to filing a written answer with the clerk, you may be required to make initial disclosures to the other parties of this suit. These disclosures generally must be made no later than 30 days after you file your answer with the clerk. Find out more at TexasLawHelp.org. Said answer may be filed by mailing same to: District Clerk’s Office, 1085 Pearl St., Room 203, Beaumont, TX 77701, or by bringing it to the office. The case is presently pending before the 58th District Court District Court of Jefferson County sitting in Beaumont, Texas, and was filed on the 18th day of July, 2025. It bears cause number 25DCCV1330 and is styled:
KEVIN C. MITCHELL VS.
CIA TRANSPORT, INC., ET AL
The name and address of the attorney for plaintiff (or plaintiff if pro se) is:
ZONA JONES
850 PARK ST.
BEAUMONT, TX. 77701
The nature of the demands of said plaintiff is shown by a true and correct copy of Plaintiff’s Order-Signed; Citation accompanying this citation and made a part thereof.
Issued under my hand and the seal of said court, at Beaumont, Texas, this the 4th day of August, 2026.
JAMIE SMITH,
DISTRICT CLERK
JEFFERSON COUNTY,
TEXAS
BY Mercedez Watler,
Mercedez Watler, Deputy
THE STATE OF TEXAS
NO. 25DCCV1330
KEVIN C. MITCHELL
VS.
CIA TRANSPORT, INC.,
ET AL
CITATION BY
PUBLICATION-
PERSON
58th DISTRICT COURT
JEFFERSON COUNTY,
TEXAS
To: My Family Moving LLC BY SERVING THE REGISTERED AGENT: ROMAN A ZENCHENKO
DEFENDANT:
SEE ATTACHED
NOTICE: You have been sued. You may employ an attorney. If you or your attorney do not file a written answer with the clerk who issued this citation by 10:00 a.m. on the Monday next following the expiration of 42 days after the date this citation was issued, a default judgment may be taken against you, the answer date being at or before 10 o’clock A.M. on Monday, September 21, 2026. In addition to filing a written answer with the clerk, you may be required to make initial disclosures to the other parties of this suit. These disclosures generally must be made no later than 30 days after you file your answer with the clerk. Find out more at TexasLawHelp.org. Said answer may be filed by mailing same to: District Clerk’s Office, 1085 Pearl St., Room 203, Beaumont, TX 77701, or by bringing it to the office. The case is presently pending before the 58th District Court District Court of Jefferson County sitting in Beaumont, Texas, and was filed on the 18th day of July, 2025. It bears cause number 25DCCV1330 and is styled:
KEVIN C. MITCHELL VS.
CIA TRANSPORT, INC., ET AL
The name and address of the attorney for plaintiff (or plaintiff if pro se) is:
ZONA JONES
850 PARK ST.
BEAUMONT, TX. 77701
The nature of the demands of said plaintiff is shown by a true and correct copy of Plaintiff’s Order-Signed; Citation accompanying this citation and made a part thereof.
Issued under my hand and the seal of said court, at Beaumont, Texas, this the 4th day of August, 2026.
JAMIE SMITH,
DISTRICT CLERK
JEFFERSON COUNTY,
TEXAS
BY Mercedez Watler,
Mercedez Watler, Deputy
NOTICE TO ALL
PERSONS HAVING CLAIMS AGAINST THE ESTATE OF
RUTHIE NELL
SINGLETON A/K/A
RUTHIE N. SINGLETON, DECEASED
Notice is hereby given that original Letters Testamentary for the Estate of RUTHIE NELL SINGLETON A/K/A RUTHIE N. SINGLETON, Deceased, were issued on July 29, 2026, in Cause No. 26CCPR0955, pending in the County Court of
Jefferson County, Texas, to ALAN SINGLETON.
The address of such Independent Executor is:
ALAN SINGLETON
c/o Bradley Law Firm
P. O. Box 1148
Port Neches, TX 77651
All persons having claims against this Estate which is currently being administered are required to present them within the time and in the manner prescribed by law.
DATED the 6th day of August 2026.
BRADLEY LAW FIRM
Attorneys at Law
P. O. Box 1148
Port Neches, TX 77651
(409) 724-6644
By: /S/Lance P. Bradley
LANCE P. BRADLEY
State Bar No. 02826650
Attorney for the Estate of RUTHIE NELL
SINGLETON A/K/A RUTHIE
N. SINGLETON, Deceased
NOTICE TO ALL PERSONS HAVING CLAIMS AGAINST THE ESTATE OF SANTA MONICA ARIAS
Notice is hereby given that original Letters Testamentary for the Estate of SANTA MONICA ARIAS, Deceased, were issued on July 22, 2026, in Cause No. 26CCPR0717, pending in the County Court of Jefferson County, Texas, to MARIA J.R. BLANCO. Claims may be presented in
care of the attorney for the Estate, addressed as follows:
MARIA J.R. BLANCO, Independent Executrix
Estate of SANTA MONICA ARIAS, Deceased
C/O Patton D. Ritter, Attorney
BTR Law
221 N. Velasco
Angleton, TX 77515
All persons having claims against this Estate, which is currently being administered, are required to present them within the time and in the manner prescribed by law.
Dated this 11th day of August 2026.
NOTICE TO DEBTORS AND CREDITORS
THE STATE OF TEXAS
§
COUNTY OF JEFFERSON
ROCHELLE ROGERS F/K/A ROCHELLE RENEE’ PINKNEY Independent Administrator for ROSE ANN HENRY F/K/A/ ROSE ANN PINKNEY, Deceased, Cause #26CCPR0953 in
Jefferson County, Texas, by the Judge of the County Court of said County on July 29, 2026, hereby notifies all persons indebted to said estate to come forward and make settlement, and those having claims against the estate to present them to him, within the time prescribed by law, c/o LAW
OFFICE OF LAIRON W. DOWDEN, JR., attorney for said estate, at 1217 Nederland Avenue,
Nederland, Texas.
WITNESS my hand this 5th day of August, 2026.
LAIRON W. DOWDEN, JR.
State Bar #06072700
(409) 724-7979
NOTICE TO CREDITORS
Notice is hereby given that original Letters Testamentary for the Estate of JESSE YARBRO, Deceased, were issued on August 6, 2026, in Cause No. 26CPR0075, pending in the County Court of CHAMBERS County, Texas, to: GENNY BELINDA BREAUX.
All persons having claims against this Estate which is currently being administered are required to present them to the undersigned within the time and in the manner prescribed by law.
c/o: P. DEAN BRINKLEY
The Brinkley Law Firm, P.C.
2905 Toccoa Road
Beaumont, Texas 77703
SIGNED on August 11, 2026.
P. Dean Brinkley /s/
Attorney for GENNY BELINDA BREAUX
State Bar No.: 00793388
2905 Toccoa Road
Beaumont, Texas 77703
Telephone: (409) 835-5800
Facsimile: (409) 835-5880
Email: dbrinkley@ctclaw.com
NOTICE TO CREDITORS
Notice is hereby given that original Letters of Testamentary were issued in The Estate of Gerald D. Corley a/k/a Gerald Don Corley, Deceased on June 23, 2026 in Cause No. 12666 in the County Court of Hardin County, Texas to Juanita Corley.
The Address of Such Independent Executor is c/o Trent Devenzio, 221 Highway 69 South, Suite 100, Nederland Texas 77627.
All persons having claims against this Estate which is currently being administered are required to present them within the time and in the manner prescribed by law.
Dated this the 23rd day of June 2026.
Juanita Corley, Independent Executor of the Estate of Gerald D. Corley a/k/a Gerald Don Corley, Deceased
NOTICE TO CREDITORS
Notice is hereby given that original Letters Testamentary for the Estate of Gilbert I. Low, Deceased, were issued on the 10th day of August, 2026, in Cause No. 26CCPR1018, pending in the County Court of Jefferson County, Texas, in Probate, to Rachael Low Roane, as Independent Executor.
All persons having claims against the Estate which is currently being administered are required to present same within the time and in the manner prescribed by law to Meredith M. Bernsen, Creighton, Fox, Johnson & Mills, PLLC, P.O. Box 5607, Beaumont, Texas 77726.
DATED this 10th day of August, 2026.
Rachael Low Roane, Independent Executor of the Estate of Gilbert I. Low, Deceased
NOTICE TO CREDITORS
Notice is hereby given that original Letters of Independent Adminstration for the Estate of JEFFREY SCOTT ROBBINS, Deceased, were issued on June 22, 2026, in Cause No. 26CCPR0511, pending in the County Court of Jefferson County, Texas, to: Lauren Martin
All persons having claims against this Estate which is currently being administered are required to present them to the undersigned within the time and in the manner prescribed by law.
c/o: Myra Gregory
Attorney at Law
1617 Magnolia Avenue
Port Neches, Texas 77651
DATED the 23rd day of June, 2026.
/s/Myra Gregory
Myra Gregory
Attorney for Carol Papania
State Bar No.: 00789091
1617 Magnolia Avenue
Port Neches, Texas 77651
Telephone: (409) 727-0900
Facsimile: (409) 727-0902
E-mail: mgregory@gregory-lawfirm.com
NOTICE TO CREDITORS
Notice is hereby given that original Letters of Independent Administration for the Estate of Joyce Ellen Kean, Deceased, were issued on August 5, 2026, in Cause No. PR-10289, pending in the County Court of Tyler County, Texas, to: Timothy Kean.
All persons having claims against this Estate which is currently being administered are required to present them to the undersigned within the time and in the manner prescribed by law.
Timothy Kean
c/o: Michael J. Lindsay
Lindsay, Lindsay & Parsons
710 North 11th Street
Beaumont, TX 77702-1502
Telephone: (409) 833-1196
Facsimile: (409) 832-7040
DATED 8th day of August, 2026.
/s/ Michael J. Lindsay
Michael J. Lindsay
State Bar No.: 12368800
RE: ESTATE OF JOHN IVAN SEABERG, DECEASED
NOTICE TO CREDITORS
Notice is hereby given that original Letters Testamentary for the Estate of John Ivan Seaberg, Deceased were issued on the 10th day of August 2026, in Cause No. 26CCPR0915 in the County Court of Jefferson County, Texas, in Probate, to Faye Hutchison Seaberg, Independent Executrix.
All persons having claims against the Estate which is currently being administered are required to present same within the time and in the manner prescribed by law. Claims may be presented in care of the attorney for the Independent Executrix addressed as follows: Faye Hutchison Seaberg, Independent Executrix, Estate of John Ivan Seaberg, Deceased, c/o Jennifer Turner Nichols, J Nichols Law, PLLC, 2935 Toccoa St., Beaumont, Texas 77703.
DATED this 11th day of August 2026.
Faye Hutchison Seaberg, Independent Executrix of the Estate of John Ivan Seaberg, Deceased
LEGAL NOTICE
Notice is hereby given in accordance with the provisions of the Texas Alcoholic Beverage Code that NS Business Group, LLC DBA NS Grocery Store has filed for a
Wine and Malt Beverage Retail Dealer’s Off-Premise Permit to be issued for 3670 Detroit St, Beaumont, Jefferson County, Texas.
MD Mondal – Managing Member
Mohosin Akon – Managing Member
/
Everett Cormier, Sr., Constable Pct. 6
Jefferson County, state of Texas
By
Chief Deputy Constable, Lester Wilson
The Minimum Bid is the lesser of 1) the amount awarded in the judgment plus interest and costs or 2) the adjudged value. However, the Minimum Bid for a person owning an interest in the property or for a person who is a party to the suit (other than a taxing unit), is the aggregate amount of the judgments against the property plus all costs of suit and sale. ALL SALES SUBJECT TO CANCELLATION WITHOUT PRIOR NOTICE. THERE MAY BE ADDITIONAL TAXES DUE ON THE PROPERTY WHICH HAVE BEEN ASSESSED SINCE THE DATE OF THE JUDGMENT.
Note: Prior to the day of the sale, a bidder must request a Statement of No Delinquent Tax Owed from the Jefferson County Tax Office. This request for statement is available on the Jefferson County Tax Office website or available at the tax office. If you are purchasing property in the name of a company, you must provide a copy of the Assumed Name Certificate, which can be obtained from the Jefferson County Clerk’s office or website, or a Franchise Tax Account Status, with a list of the officers and directors, which may obtain from the Texas Comptroller’s Office Website. If you are not an officer or director of the company, you must also provide a letter on company letterhead signed by an officer or director, giving you authorization to bid on behalf of the company.
A bidder at the sale must be registered, at the time the sale begins, with the person conducting the sale. The bidder must submit the letter (Statement of No Delinquent Taxes Owed) to the person conducting the sale. Once the sale begins at 10:00 a.m., no one will be allowed to obtain a bidder number.