LEGAL NOTICE
September 17, 2026
Notice is hereby given that sealed Proposals will be accepted by the Jefferson County Drainage District No. 6 Purchasing Department for RFP 26-029/KKJ, Grant Administration and
Management Services for
Community Development
Block Grant-Mitigation
Reallocation Program
(CDBG-MRP) for Jefferson County Drainage District No. 6.
Drainage District No. 6 plans to apply for the upcoming Mitigation Reallocation Program (MRP) from the Texas General Land Office (GLO) through the U.S. Department of Housing and Urban Affairs (HUD) These services are being solicited to assist the District in its application and administration of CDGB-MRP contract(s), if awarded, to support eligible activities. Accordingly, the District is seeking to contract with a qualified Grant Administration Service Provider (individual/firm) to prepare the application and/or administer the awarded contract(s). Specifications for this project may be obtained from the Jefferson County Drainage District No. 6 webpage
https://dd6.org/departments/purchasing/notices-for-bid/
Proposals are to be sealed and addressed to the Purchasing Department with the Proposal number and name marked on the outside of the envelope or box. Proposers shall forward an original and five (5) hard copies of their Proposal to the address shown below. Late Proposals will be rejected as non-responsive. Proposals will be publicly opened and only the firm name will be read aloud in at Jefferson County Drainage District No. 6 main facilities at the time and date below. Proposals shall be opened in a manner that avoids disclosure of the contents to competing Proposers and maintains the confidentiality of the Proposals during negotiations. Proposers are invited to attend the sealed Proposal opening.
BID NAME: Grant Administration and Management Services for Community Development Block Grant-Mitigation Reallocation Program (CDBG-MRP)
BID NO: RFP 26-029/KKJ
DUE DATE: 2:00 PM, October 8, 2026
MAIL OR DELIVER TO: Jefferson County Drainage District No. 6
Purchasing Department
6550 Walden Rd.
Beaumont, Texas 77707
Any questions relating to these requirements should be directed to Karen K. Johnson, Chief Business Officer kjohnson@dd6.org Jefferson County Drainage District No. 6 is an Affirmative Action/Equal Opportunity Employer and encourages Section 3 Residents, Minority Business Enterprises, Small Business Enterprises, and Women-owned Business Enterprises to submit Proposals. The District does not discriminate on the basis of race, color, national origin, sex, religion, age or disability in employment or the provisions of services. The District reserves the right to accept or reject any or all Proposals, to waive technicalities and to take whatever action is in the best interest of the District.
Karen K. Johnson, MBA, CTCD, CTCM Chief Business Officer Jefferson County Drainage District No. 6, Texas
LEGAL NOTICE
Advertisement for
Invitation for Bids
September 17, 2026
Notice is hereby given that sealed bids will be accepted by Jefferson County Drainage District No. 6 for a (IFB 26-030/SC) Equipment Storage Building Project for Jefferson County Drainage District No. 6. Specifications for this project may be obtained from the Jefferson County Drainage District No. 6 webpage https://dd6.org/departments/purchasing/notices-for-bid/
Bids are to be sealed and addressed to Jefferson County Drainage District No. 6 and marked “Administrative Sealed Bid” with (IFB 26-030/SC) Equipment Storage Building Project, for Jefferson County Drainage District No. 6” on the outside of the envelope. Bidders shall forward an original and two (2) copies of their bid to the address shown below. The District does not accept bids submitted electronically. Late bids will be rejected as non-responsive. Administrative bids will be publicly opened and read aloud in the Jefferson County Drainage District No. 6 boardroom at the time and date below. Bidders are invited to attend the bid opening.
BID NAME: Equipment Storage Building Project BID NUMBER: IFB 26-030/SC
DUE DATE/TIME: 2:00 PM, October 1, 2026
MAIL OR DELIVER TO: Jefferson County Drainage District No. 6 6550 Walden Rd. Beaumont, Texas 77707
Any questions relating to these requirements should be directed to Shelby Clodfelter, Buyer/Contract Administrator II, at 409-842-1818 or sclodfelter@dd6.org.
Jefferson County Drainage District No. 6 reserves the right to accept or reject any or all bids, to waive technicalities and to take whatever action is in the best interest of the District.
All interested vendors are invited to submit a bid in accordance with the terms and conditions stated in this bid.
RESPONDENTS ARE STRONGLY ENCOURAGED TO CAREFULLY READ THE ENTIRE INVITATION
Karen K. Johnson, MBA, CTCD, CTCM
Chief Business Officer
Jefferson County Drainage District No. 6, Texas
INVITATION TO BIDDERS
Bids will be received by the City of Beaumont, Beaumont, Texas, until 2:00 P.M. (CT), THURSDAY, OCTOBER 8, 2026, and all bids will be opened and publicly read in the City Council Chambers on that date for:
Contract for Pavement Improvements at
Charlton Pollard Park
Located at 2060 Irving Ave., Beaumont,
Texas 77701
A MANDATORY Pre-Bid meeting will be held on Friday, September 25, 2026, 2026, at 10:00 A.M. (CT), at the Charlton Pollard Park, located at 2060 Irving Ave., Beaumont, TX 77701.
Questions about the bid must be submitted by 10:00 A.M. (CT) on Monday, October 5, 2026. Answers to the questions may be provided through an Addendum.
Bidding forms, specifications and all necessary information may be downloaded from the City’s e-bids platform at: https://beaumonttexas.ionwave.net/Login.aspx.
Bids must be submitted through the City’s e-bids platform at: https://beaumonttexas.ionwave.net/Login.aspx. Vendors must register to submit a bid or proposal.
The City reserves the right to reject any or all bids, or to accept any bid or combination of bids deemed advantageous to it.
Please make reference to Bid Number: MF0923-53
Bid Closing Date:
OCTOBER 8, 2026
Tina Broussard, TRMC
City Clerk
LEGAL NOTICE
The following property has been declared to be an Unsafe Structure by the Building Codes Division of the City of Beaumont under the guidelines of Article 24.04, Sections 24.04.001 and 24.04.002 of the Code of
Ordinances. This is to serve as notice that as provided in the Code of Ordinances; the property will be brought
before the Beaumont City Council at a Public Hearing on October 6th, 2026.
Address
1. 1775 College
Legal Description
BLANCHETTE 1 C1/3 OF L43 TO 45 B 6
Boyd Meier Building Official City of Beaumont
801 Main Street
Beaumont, Texas 77701 (409) 880-3762
NOTICE TO BIDDERS
REQUEST FOR
PROPOSAL (RFP)
Baptist Hospital of
Southeast - Evolv Express Gen 2 Dual-Lane
Weapons Detection System
Issuing Entity Baptist Hospitals of Southeast Texas
Submission Due Date October 1, 2026, 2:00pm
Sole Point of Contact Reginald Wasson, Safety Officer, rwasson@bhset.net, 409-828-8112
Baptist Hospitals of Southeast Texas is requesting proposals from qualified vendors to furnish, install, configure, commission, and support one Evolv Express Gen 2 dual-lane concealed weapons detection system for Baptist Hospital of
Southeast Texas Main Campus. The work includes the dual-lane hardware, software and services subscription, specified
peripheral equipment, on-site support, user training, go-live assistance, shipping, testing, and turnover.
PROJECT PURPOSE AND BACKGROUND
The project is intended to add a modern concealed weapons detection capability at a designated facility entrance while
supporting efficient movement of patients, visitors, staff, and vendors. Evolv Express uses advanced sensor technology and artificial intelligence to identify potential threats and distinguish them from many common everyday items. The system is intended to support, not replace, a layered security program combining trained personnel, operating procedures, and technology.
BASE SCOPE OF WORK
● Primary System: furnish one Evolv Express Gen 2 dual-lane hardware purchase, standard configuration, manufacturer
SKU 901-00011-00-HP.
● Software and Services: provide one Evolv Express Gen 2 dual-lane software and services subscription for an Evolv purchase, standard, manufacturer SKU 901-00012-00-SS-HP, for a 60-month subscription term.
● Included Dual-Lane Configuration: one transmit tower, two receive towers, two standard/wide-width adjustable mats, one country-specific 6-foot power cord, installation kit with bolt-down kit, two 10-inch wireless tablets on floor stands, two 10-inch wireless tablets on desktop stands, four spare tablet batteries, and one one-slot external tablet battery charger.
● Peripheral Equipment and Services: include one Evolv Express Operational Test Kit, SKU 101-00257-01; one DTR Tablet Battery Charger, 6-Slot, SKU 390-00256; one DTR Tablet Replacement Battery, 90W, SKU 390-00255; one Pull Handle Kit, SKU 101-00598-01; one day of on-site support, SKU 610-00001; one day of installation, user training, and go-live services, SKU 610-00036; and all required shipping/freight.
CONTRACTOR QUALIFICATION REQUIREMENTS
● Respondents shall be authorized and qualified to furnish, install, configure, and support Evolv Technologies, Inc. products and shall identify applicable manufacturer authorization, training, and support credentials.
● Respondents shall provide personnel experienced with concealed weapons detection systems and entrance-screening operations in active healthcare or similarly occupied environments.
● Respondents shall provide the specified Evolv Express Gen 2 dual-lane system and listed manufacturer SKUs. Any proposed substitution or deviation shall be clearly identified, fully documented, and subject to owner approval.
● Respondents shall coordinate installation and go-live activities with hospital security, facilities, and information
technology representatives to minimize disruption and preserve safe access.
● Respondents shall describe the proposed technical support, maintenance, preventative maintenance, break-fix
response, training, escalation, and warranty/service coverage for the full subscription term.
PROPOSAL SUBMISSION REQUIREMENTS
● Narrative proposal describing the respondent’s approach to procurement, delivery, installation, configuration, testing, user training, go-live, and turnover.
● Itemized pricing for hardware, software and services subscription, peripheral equipment, installation, on-site support,
training, shipping/freight, taxes, and any optional services.
● Equipment schedule listing manufacturer, product description, quantity, manufacturer SKU, subscription assumptions,
included accessories, proposed substitutions, and exclusions.
● Project schedule showing order placement, anticipated delivery, site readiness review, installation, operational testing, training, go-live, and final acceptance milestones.
● Description of support availability, response and escalation process, maintenance coverage, software updates, warranty terms, and owner support responsibilities.
● Copies of applicable business licenses, insurance, manufacturer authorization or partner credentials, and subcontractor qualifications.
● References for comparable concealed weapons detection deployments in hospitals, healthcare facilities, or other
occupied public-facing environments, if available.
● List of assumptions, exclusions, site readiness requirements, electrical and network dependencies, owner-furnished items, required site access, and acceptance criteria.
FEDERALLY FUNDED SELECTION CRITERIA
Evaluation Category
Evolv Express Gen 2 dual-lane technical proposal
Weight
35%
Requested Contents
Specified hardware and SKUs, dual-lane configuration, software and
services subscription, site requirements, testing, commissioning, and
acceptance plan.
Evaluation Category
Installation, training, go-live, and support plan
Weight
25%
Requested Contents
Installation approach, operational test kit use, user training, go-live assistance, maintenance, technical support, escalation, and
warranty/service coverage.
Evaluation Category
Proposed completion time and implementation readiness
Weight
20%
Requested Contents
Procurement and delivery assumptions, site readiness dependencies, installation schedule, training, go-live, and turnover milestones.
Evaluation Category
Past performance in healthcare or occupied facilities
Weight
15%
Requested Contents
Comparable concealed weapons detection or entrance-screening
deployments in hospitals, healthcare facilities, or other occupied public-facing environments.
Evaluation Category
Past work experience with Baptist Hospitals of Southeast Texas
Weight
5%
Requested Contents
Prior work history, familiarity with owner standards, and demonstrated
ability to coordinate with hospital security, facilities, and information
technology stakeholders.
GENERAL CONDITIONS
● Failure to apprise oneself of hospital, facility, state, local, federal, licensing, code, safety, procurement, and grant-related requirements will not excuse any bidder from compliance with applicable requirements.
● All delivery, installation, testing, training, and go-live work shall be coordinated with facility representatives to minimize disruption and maintain safe access for patients, visitors, staff, vendors, and tenants.
● The owner reserves the right to reject any or all bids, waive informalities, request clarification, negotiate scope, and request new bids for the whole or any portion of the work.
● The owner may reject incomplete proposals, proposals that do not demonstrate required qualifications or manufacturer support capability, and proposals that fail to address the specified Evolv Express Gen 2 dual-lane scope and
submission requirements.
● This notice is intended as a bid solicitation summary. The final RFP package, drawings, site conditions, and owner-issued addenda shall govern the work.
Source Basis Used to Prepare Notice
● Baptist Hospitals of SE Texas - dual lane.pdf - Used for the quoted Evolv Express Gen 2 dual-lane configuration, manufacturer SKUs, quantities, 60-month term, peripheral equipment, services, and shipping
requirements.
● Evolv Express official product information at evolvtechnology.com - Used for manufacturer product
description, concealed weapons detection purpose, advanced sensor and artificial intelligence description, operator-support functions, and layered-security qualifications.
● Evolv Express official solution brief - Used for product positioning, entrance-flow objectives, threat-location alerts, analytics, and operational context.
NOTICE OF SALE
THE STATE OF TEXAS
COUNTY OF JEFFERSON
§
BY VIRTUE OF AN ORDER OF SALE
and issued pursuant to a judgment decree of the 58th District Court of Jefferson County, Texas, by the Clerk of said Court on said date in a certain suit No. 23DCCV1932 and styled Panacea Fund I, LLC vs Janis Marie Hairgrove, ET AL, and to me directed and delivered as Constable of said County, I have on the 4th day of September, 2026, Seized, levied upon, and will on the first Tuesday in October, 2026, the same being the 6th day of said month, at the Courthouse of Jefferson County, in the City of Beaumont, between the hours of 10:00 o’clock a.m. and 4:00 o’clock p.m. on said day, proceed to sell for cash to the highest bidder all of the right, title, and interest of the defendants in such suit in and to the following described real estate levied upon as the property of said defendants, the same lying and being situated in the County of Jefferson and State of Texas, to wit:
Cause#23DCCV1932 Panacea Fund I, LLC. Vs. Janis Marie Hairgrove, Et Al Judgement date: March 25, 2025 Property ID#15488 Geographic ID:009300-000-010300-00000 LOT 117 CALDER TERRACE ADDITION TO THE CITY OF BEAUMONT, JEFFERSON COUNTY, TEXAS, ACCORDING TO THE MAP OR PLAT OF RECORD IN VOLUME 4, PAGE 193, MAP RECORDS IN THE OFFICE OF THE COUNTY CLERK OF SAID COUNTY.
Commonly known as: 175 W. Circuit Dr., Beaumont, TX 77706 Judgement Amount: $100,629.17 plus penalties and interest that has accrued from March 25, 2025.
or upon the written request of said defendants or their attorney, a sufficient portion thereof to satisfy said judgment, interest, penalties and costs; subject, however, to the right of redemption the defendants or any person having an interest therein, to redeem the said property, or their interest therein, at any time within two (2) years from the recordation of the deed, on residential homestead and agricultural use property, for all other property the owner’s right of redemption may be executed not later than the 180th day following the date on which the purchaser’s or taxing unit’s deed is filed for record, in the manner provided by law, and subject to any other and further rights to which the defendants or anyone interested therein may be entitled, under the provisions of law. Said sale to be made by me to satisfy the judgment rendered in the above styled and numbered cause, together with interest, penalties and costs of suit, and the proceeds of said sale to be applied to the satisfaction thereof, and the remainder, if any, to be applied as the law directs.
NOTES: ALL SALES SUBJECT TO CANCELLATION WITHOUT PRIOR NOTICE. This property may have other liens, taxes due or encumbrances, which may become the responsibility of the successful bidder.
Dated this the 4th day of September, 2026, at Beaumont, Texas.
Jefferson County Constable’s Office Precinct1, Texas
/s/ Jevonne “J.C.” Pollard
BY: Jevonne “J.C” Pollard Constable of Jefferson County Precinct 1, TEXAS
Notice of
Foreclosure Sale
THE STATE OF TEXAS )
COUNTY OF JEFFERSON)
THIS NOTICE OF FORECLOSURE IS GIVEN pursuant to Tex. Tax Code Chapter 34, and Tex. R. Civ. P. 21a., by virtue of an Order of Sale issued on July 16, 2026, pursuant to the
Judgment rendered in favor of the plaintiffs and/or intervenors on May 21, 2026 by the 136th Judicial District Court in Jefferson County, Texas, in Cause No. 25DCCV0740 styled JEFFERSON COUNTY, ET AL vs. JOHN YORK, ET AL, on July 21, 2026, I levied, against all legal interest and/or right of all defendants subject to said Judgment, upon the following described tracts or parcels of land:
STREET ADDRESS: 6825 Willis Ln, Beaumont, TX 77708;
TAX ACCOUNT NUMBER(S): 003850-000-030100-00000; and
LEGAL DESCRIPTION: BEL AIR L 4 B 21; and being more particularly described as Lot Number Four (4), in Block Number Twenty-One (21), Bel Air Addition to the City of Beaumont, Jefferson County, Texas, according to the Map or Plat of Record in the Office of County Clerk in Volume 8, Page 38 of the Map Records of said County and State.
On October 6, 2026, being the first Tuesday of said month, between the hours of 10:00 am and 4:00 pm, at the most northerly entrance of the newest addition to the Courthouse, Beaumont, Texas, I will offer for sale and sell at public auction, for cash, all the right, title, and interest of all defendants subject to said Judgment, in and to said tracts or parcels of land, as provided for by
the Texas Tax Code, to satisfy said Judgment for delinquent property taxes, accrued penalties, interests, and attorney’s fees, totaling $39,626.85, plus all post judgment interest, penalties, court costs and costs of sale awarded therein and pursuant to the Texas Tax Code, due on said tracts or
parcels of land. The sale shall begin no earlier than 10:00 a.m. and no later than three hours thereafter. The sale shall be completed by three hours after it commences or 4:00 p.m.,
whichever occurs first. I hereby verify, certify and declare under penalty of perjury that I delivered a true and correct copy of this Notice of Foreclosure Sale by Certified Mail and First-
Class Mail through the United States Postal Service, return receipt requested, to each of the
defendant named in said Judgment.
“THIS SALE IS BEING CONDUCTED PURSUANT TO STATUTORY OR JUDICIAL REQUIREMENTS. BIDDERS WILL BID ON THE RIGHTS, TITLE, AND INTERESTS, IF ANY, IN THE REAL PROPERTY OFFERED.
“THE PROPERTY IS SOLD AS IS, WHERE IS, AND WITHOUT ANY WARRANTY, EITHER EXPRESS OR IMPLIED. NEITHER THE SELLER NOR THE SHERIFF’S DEPARTMENT WARRANTS OR MAKES ANY REPRESENTATIONS ABOUT THE PROPERTY’S TITLE, CONDITION,
HABITABILITY, MERCHANTABILITY, OR FITNESS FOR A PARTICULAR PURPOSE. BUYERS ASSUME ALL RISKS.
“IN SOME SITUATIONS, A LOT OF FIVE ACRES OR LESS IS PRESUMED TO BE INTENDED FOR RESIDENTIAL USE. HOWEVER, IF THE PROPERTY LACKS WATER OR WASTEWATER SERVICE, THE PROPERTY MAY NOT QUALIFY FOR RESIDENTIAL USE. A POTENTIAL BUYER WHO WOULD LIKE MORE INFORMATION SHOULD MAKE ADDITIONAL INQUIRIES OR CONSULT WITH PRIVATE COUNSEL.”
“ESTA VENTA SE LLEVA A CABO CONFORME A LOS REQUISITOS ESTATUTARIOS O JUDICIALES. LOS OFERTANTES PRESENTARÁN SUS OFERTAS SOBRE LOS DERECHOS, TÍTULO E INTERESES, SI LOS HUBIERE, DEL BIEN INMUEBLE EN VENTA.
“LA PROPIEDAD SE VENDE ASÍ COMO ESTÁ, DÓNDE ESTÁ, Y SIN NINGUNA GARANTÍA, NI EXPLÍCITA NI IMPLÍCITA. NI EL VENDEDOR NI EL DEPARTAMENTO DEL SHERIFF ASEGURA NI DECLARA NADA EN CUANTO AL TÍTULO DE PROPIEDAD, LA CONDICIÓN, HABITABILIDAD, COMERCIABILIDAD O IDONEIDAD PARA UN DETERMINADO PROPÓSITO. LOS COMPRADORES ASUMEN TODOS LOS RIESGOS.
“EN ALGUNAS SITUACIONES, UN LOTE DE CINCO ACRES O MENOS SE PRESUME QUE ESTÉ DESTINADO PARA USO RESIDENCIAL. SIN EMBARGO, SI LA PROPIEDAD NO CUENTA CON EL SERVICIO DE AGUAS BLANCAS O AGUAS NEGRAS, PUEDE QUE NO CALIFIQUE PARA USO RESIDENCIAL. UN POSIBLE CLIENTE QUE DESEE MAYOR INFORMACIÓN DEBERÁ INVESTIGAR MÁS O ASESORARSE CON UN ABOGADO.”
Dated at Jefferson County, Texas this 18th day of August, 2026.
Jefferson County Constable’s Office
By: Jevonne Pollard
Constable of Jefferson County
Precinct 1, Texas
THE STATE OF TEXAS
CITATION BY PUBLICATION
TO: UNKNOWN HEIRS OF
COREY BRYANT HEIDENRICH, DECEASED
DEFENDANT(S) GREETING:
YOU ARE HEREBY COMMANDED to appear before the Honorable Probate County Court of Jefferson County, Texas, at the Courthouse in the City of Beaumont, at or before 10 o’clock a.m. of the first Monday after the expiration of ten (10) days from the date of issuance thereof, same being Monday, 09/28/2026 then and there to answer the proceeding to declare heirship filed by Adam Heidenrich, Applicant, in said Court 09/15/2026 in Cause No. 26CCPR1269, styled,
In the Estate of:
COREY BRYANT HEIDENRICH, DECEASED
A brief statement of the nature of the petition is as follows, to-wit:
DETERMINE THE HEIRS AND THEIR RESPECTIVE, SHARES & INTERESTS UNDER THE LAWS OF THIS STATE OR IN THE TRUST, AS APPLICABLE IN THE DECEDENT’S ESTATE
as is more fully shown by the petition on file in this cause.
The officer executing this process shall promptly execute the same according to law and make due return as the law directs. If this citation is not served within (90) days after day of issuance, it shall be returned unserved.
Issued and given under my hand and seal of said Court at Beaumont, Texas, on this 15th day of September, 2026.
Roxanne Acosta-Hellberg, County Clerk
Jefferson County, Texas
By Christy Johnson,
Christy Johnson,
Deputy Clerk
NOTICE OF SALE
THE STATE OF TEXAS
§
COUNTY OF JEFFERSON
§
BY VIRTUE OF AN Order of Sale and issued pursuant to judgment decree(s) of the 172nd District Court of Jefferson County, Texas, by the Clerk of said Court on said date, in the hereinafter numbered and styled suit(s) and to me directed and delivered as Sheriff or Constable of said County, I have on 08-18-26, 2026, seized, levied upon, and will, on the first Tuesday in October, 2026, the same being the 6th day of said month, inside the Jefferson County Courthouse, in the city of Beaumont, Texas, located at 1149 Pearl Street, Beaumont, Texas 77701, between the hours of 10 o’clock a.m. and 4 o’clock p.m., beginning at approximately 10:00 a.m., on said day, proceed to sell for cash to the highest bidder all the right, title, and interest of the defendants in such suit(s) in and to the following described real estate levied upon as the property of said defendants, the same lying and being situated in the County of Jefferson and the State of Texas, to-wit:
Cause #: 24DCCV0906 RESOLUTION FINANCE, LLC v. CONSTANCE S. O’BRIEN-LITTLE; Judgment Date: March 12, 2026 Property ID: 03995000003080000000, Order of Sale Issued: May 21, 2026
Legal Description: THAT CERTAIN APARTMENT DESIGNATED AS UNIT EIGHT (8), IN BUILDING ‘B’, OF THE MANION PLACE TOWNHOMES, SECTION SEVENTEEN (17), A CONDOMINUM PROJECT IN BEAUMONT, JEFFERSON COUNTY, TEXAS, INCLUDING THE PATIO SPACE AND THE GARAGE ASSIGNED THERETO, AND AN UNDIVIDED INTEREST IN THE COMMON ELEMENTS THEREOF, ACCORDING TO THE CONDOMINIUM DECLARATION AND BY-LAWS WHICH ARE RECORDED IN VOLUME 4, PAGE 312, AND THE PLAT THEREOF BEING RECORDED IN VOLUME 2, PAGE 64, ALL IN THE CONDOMINIUM RECORDS OF JEFFERSON COUNTY, TEXAS.
Commonly known as: 6075 Fairmeadow St, Beaumont Texas 77707
Judgment Amount: $62,297.17 plus penalties and interest that has accrued from March 12, 2026
any volume and page references, unless otherwise indicated, being to the Deed Records, Jefferson County, Texas, to which instruments reference may be made for a more complete description of each respective tract.) or, upon the written request of said defendants or their attorney, a sufficient portion of the property described above shall be sold to satisfy said judgment(s) interest, penalties, and cost. Said sale to be made by me to satisfy the judgment(s) rendered in the above styled and numbered cause(s), together with interest, penalties, and costs of suit, and the proceeds of said sales to be applied to the satisfaction thereof, and the remainder, if any, to be applied as the law directs.
NOTES: ALL SALES SUBJECT TO CANCELLATION WITHOUT PRIOR NOTICE. This property may have other liens, taxes due or encumbrances, which may become the responsibility of the successful bidder.
Dated at Beaumont, Texas August 18, 2026
Constable, Jevonne Pollard,
Jefferson County, Texas
By: /s/ Jevonne Pollard.
Deputy
THE STATE OF TEXAS
CITATION BY
PUBLICATION
TO: UNKNOWN HEIRS OF
AXEL CHRISTOPHER MIKAEL WILLIAMS, DECEASED
DEFENDANT(S)
GREETING:
YOU ARE HEREBY COMMANDED to appear before the Honorable Probate County Court of Jefferson County, Texas, at the Courthouse in the City of Beaumont, at or before 10 o’clock a.m. of the first Monday after the expiration of ten (10) days from the date of issuance thereof, same being Monday, 09/28/2026 then and there to answer the proceeding to declare heirship filed by Monica Rose Williams, Applicant, in said Court 09/14/2026 in Cause No. 26CCPR1268, styled,
In the Estate of:
AXEL CHRISTOPHER MIKAEL WILLIAMS, DECEASED
A brief statement of the nature of the petition is as follows, to-wit:
DETERMINE THE HEIRS AND THEIR RESPECTIVE, SHARES & INTERESTS UNDER THE LAWS OF THIS STATE OR IN THE TRUST, AS APPLICABLE IN THE DECEDENT’S ESTATE
as is more fully shown by the petition on file in this cause.
The officer executing this process shall promptly execute the same according to law and make due return as the law directs. If this citation is not served within (90) days after day of issuance, it shall be returned unserved.
Issued and given under my hand and seal of said Court at Beaumont, Texas, on this 15th day of September, 2026.
Roxanne Acosta-Hellberg, County Clerk
Jefferson County, Texas
By Victoria Frasier,
Victoria Frasier,
Deputy Clerk
THE STATE OF TEXAS
No. 26DCCV1163
FINANCE OF AMERICA REVERSE, LLC
VS.
THE UNKNOWN HEIRS AT LAW OF GEORGE PICKENS JR., DECEASED, ET AL.
CITATION BY
PUBLICATION –
UNKNOWN HEIRS AT LAW OF GEORGE
PICKENS, JR.,
DECEASED
172ND DISTRICT COURT JEFFERSON COUNTY, TEXAS
To: THE UNKNOWN HEIRS AT LAW OF GEORGE PICKENS, JR., DECEASED
DEFENDANT:
LOT 3, BLOCK 82, CARTWRIGHT ADDITION, CITY OF BEAUMONT, JEFFERSON COUNTY, TEXAS, ACCORDING TO MAP OR PLAT THEREOF RECORDED IN VOLUME 1 PAGE 137 OF THE MAP AND/OR PLAT RECORDS OF JEFFERSON COUNTY, TEXAS
NOTICE: You have been sued. You may employ an attorney. If you or your attorney do not file a written answer with the clerk who issued this citation by 10:00 a.m. on the Monday next following the expiration of 42 days after the date this citation was issued, a default judgment may be taken against you, the answer date being at or before 10 o’clock A.M. on Monday, October 12, 2026. In addition to filing a written answer with the clerk, you may be required to make initial disclosures to the other parties of this suit. These disclosures generally must be made no later than 30 days after you file your answer with the clerk. Find out more at TexasLawHelp.org Said answer may be filed by mailing same to: District Clerk’s Office, 1085 Pearl St., Room 203, Beaumont, TX 77701, or by bringing it to the office. The case is presently pending before the 172nd District Court of Jefferson County sitting in Beaumont, Texas, and was filed on the 8th day of June, 2026. It bears cause number 26DCCV163 and is styled:
FINANCE OF AMERICA REVERSE, LLC
vs. THE UNKNOWN HEIRS AT LAW OF GEORGE PICKENS JR., DECEASED, ET AL.
The name and address of the attorney for plaintiff (or plaintiff if pro se) is:
JOSEPH VACEK
ROBERTSON ANSCHUTZ ET AL
5601 EXECUTIVE DR., STE. 400
IRVING, TX 75038
Issued under my hand and the seal of said court, at Beaumont, Texas, this the on this the 27th day of August 2026.
JAMIE SMITH,
DISTRICT CLERK
JEFFERSON COUNTY, TEXAS
BY Erin Harper,
Erin Harper, Deputy
THE STATE OF TEXAS
CITATION BY
PUBLICATION
TO: UNKNOWN HEIRS OF
EARL WALKER,
DECEASED
DEFENDANT(S)
GREETING:
YOU ARE HEREBY COMMANDED to appear before the Honorable Probate County Court of Jefferson County, Texas, at the Courthouse in the City of Beaumont, at or before 10:00 o’clock a.m. of the first Monday after the expiration of ten (10) days from the date of issuance thereof, same being Monday, 09/28/2026 then and there to answer the proceeding to declare heirship filed by Jaqueline Warren, Applicant, in said Court 08/27/2026 in Cause No. 26CCPR0001, styled,
In the Estate of:
EARL WALKER, DECEASED
A brief statement of the nature of the petition is as follows, to-wit:
DETERMINE THE HEIRS AND THEIR RESPECTIVE, SHARES & INTERESTS UNDER THE LAWS OF THIS STATE OR IN THE TRUST, AS APPLICABLE IN THE DECEDENT’S ESTATE
as is more fully shown by the petition on file in this cause.
The officer executing this process shall promptly execute the same according to law and make due return as the law directs. If this citation is not served within (90) days after day of issuance, it shall be returned unserved.
Issued and given under my hand and seal of said Court at Beaumont, Texas, on this 15th day of September, 2026.
Roxanne Acosta-Hellberg, County Clerk
Jefferson County, Texas
By Reagan Dixon,
Reagan Dixon,
Deputy Clerk
THE STATE OF TEXAS
No. 26DCCV1455
FREEDOM MORTGAGE CORPORATION
VS.
MICHELLE KIBBE, ET AL.
CITATION BY PUBLICATION –
THE UNKNOWN HEIRS AT LAW OF CHRIS KIBBE, DECEASED
136TH DISTRICT COURT JEFFERSON COUNTY, TEXAS
To: THE UNKNOWN HEIRS AT LAW OF CHRIS KIBBE, DECEASED
DEFENDANT:
SEE ATTACHED
NOTICE: You have been sued. You may employ an attorney. If you or your attorney do not file a written answer with the clerk who issued this citation by 10:00 a.m. on the Monday next following the expiration of 42 days after the date this citation was issued, a default judgment may be taken against you, the answer date being at or before 10 o’clock A.M. on Monday, October 26, 2026. In addition to filing a written answer with the clerk, you may be required to make initial disclosures to the other parties of this suit. These disclosures generally must be made no later than 30 days after you file your answer with the clerk. Find out more at TexasLawHelp.org Said answer may be filed by mailing same to: District Clerk’s Office, 1085 Pearl St., Room 203, Beaumont, TX 77701, or by bringing it to the office. The case is presently pending before the 136th District Court District Court of Jefferson County sitting in Beaumont, Texas, and was filed on the 17th day of July, 2026. It bears cause number 26DCCV1455 and is styled:
FREEDOM. MORTGAGE CORPORATION VS.
MICHELLE KIBBE, ET AL.
The name and address of the attorney for plaintiff (or plaintiff if pro se) is:
TENIA OUELLETTE
TROMBERG, MILLER, MORRIS & PARTNERS, PLLC
6080 TENNYSON PRKWAY SUITE 100
PLANO, TX 75024
The nature of the demands of said plaintiff is shown by a true and correct copy of Plaintiff’s Order for Substitute/Alternate Service accompanying this citation and made a part thereof.
Issued under my hand and the seal of said court, at Beaumont, Texas, this the 11th day of September, 2026.
JAMIE SMITH,
DISTRICT CLERK
JEFFERSON COUNTY, TEXAS
BY Erin Harper,
Erin Harper, Deputy
THE STATE OF TEXAS
No. 25DCCV1804
NatiONSTAR MORTGAGE
VS.
MELISSA VIDRINE, ET AL
CITATION BY
PUBLICATION –
THE UNKNOWN HEIRS AT LAW OF JOHNNY HOLLOWAY, DECEASED
60th DISTRICT COURT JEFFERSON COUNTY, TEXAS
To: THE UNKNOWN HEIRS AT LAW OF JOHNNY HOLLOWAY, DECEASED
DEFENDANT:
LOT NO. TEN (10), IN BLOCK NO. THREE (3), OF HAWTHORNE PLACE ADDITION, UNIT ONE, TO THE CITY OF BEAUMONT, JEFERSON COUNTY, TEXAS, ACCORDING TO THE MAP OR PLAT OF RECORD IN VOL. 7, PAGE 165, MAP RECORDS OF JEFFERSON COUNTY, TEXAS.
NOTICE: You have been sued. You may employ an attorney. If you or your attorney do not file a written answer with the clerk who issued this citation by 10:00 a.m. on the Monday next following the expiration of 42 days after the date this citation was issued, a default judgment may be taken against you, the answer date being at or before 10 o’clock A.M. on Monday, November 2, 2026. In addition to filing a written answer with the clerk, you may be required to make initial disclosures to the other parties of this suit. These disclosures generally must be made no later than 30 days after you file your answer with the clerk. Find out more at TexasLawHelp.org Said answer may be filed by mailing same to: District Clerk’s Office, 1085 Pearl St., Room 203, Beaumont, TX 77701, or by bringing it to the office. The case is presently pending before the 60th District Court District Court of Jefferson County sitting in Beaumont, Texas, and was filed on the 5th day of September, 2025. It bears cause number 25DCCV1804 and is styled:
NATIONSTAR MORTGAGE VS. MELISSA VIDRINE, ET AL.
The name and address of the attorney for plaintiff (or plaintiff if pro se) is:
TENIA OUELLETTE
TROMBERG, MILLER, MORRIS & PARTNERS, PLLC
6080 TENNYSON PRKWAY SUITE 100
PLANO, TX 75024
The nature of the demands of said plaintiff is shown by a true and correct copy of Plaintiff’s Order for Substitute/Alternate Service accompanying this citation and made a part thereof.
Issued under my hand and the seal of said court, at Beaumont, Texas, this the 16th day of September, 2026.
JAMIE SMITH,
DISTRICT CLERK
JEFFERSON COUNTY, TEXAS
BY Erin Harper,
Erin Harper, Deputy
NOTICE TO CREDITORS
Notice is hereby given that original Letters Testamentary for the Estate of Edward Lee LeBlanc, Jr., Deceased, were issued on September 16, 2026, in Cause No. 2026-0173-PR,
pending in the County Court of Orange County, Texas, to: Sheree Leblanc Gutierrez.
All persons having claims against this Estate which is currently being administered are required to present them to the undersigned within the time and in the manner prescribed by law.
c/o: Representative,
Estate of Edward Lee
LeBlanc, Jr.
Ramsey Law
6280 Delaware Street, Suite A
Beaumont, Texas 77706
DATED the 16TH day of September, 2026.
/s/ Randal Cashiola
Randal Cashiola, Of Counsel
RAMSEY LAW
Attorney for Sheree Leblanc Gutierrez
State Bar No.: 03966802
6280 Delaware Street, Suite A
Beaumont, Texas 77706
T: 409.444.2020
F: 409.444.2021
ramseydocket@ramseylaw.com
CAUSE NO. 2026-0174-PR
IN THE ESTATE OF CARLOS RAY VACEK, DECEASED
§
IN THE COUNTY COURT OF ORANGE COUNTY, TEXAS
PROBATE DIVISION
NOTICE TO CREDITORS
Notice is hereby given that original Letters of Testamentary for the Estate of CARLOS RAY VACEK, Deceased, were issued on September 14, 2026, under Cause No. 2026-0174-PR, pending in the County Court of Orange County, Texas, Probate Division, to ELIZABETH ANN VACEK.
Claims may be presented in care of the attorney for the Independent Executor, addressed as follows:
Estate of Carlos Ray Vacek, Deceased
Attn: Elizabeth Ann Vacek, Independent Executor
c/o Christopher D. Leavins Germer PLLC
P. O. Box 4915
Beaumont, Texas 77704 Phone: (409) 654-6700 Fax: (409) 835-2115
All persons having claims against this estate, which is currently being administered, are required to present them within the time and in the manner prescribed by law.
Dated this 16th day of September 2026.
GERMER PLLC
550 Fannin Street, Suite 400
P.O. Box 4915
Beaumont, Texas 77704 (409) 654-6700 - Telephone (409) 835-2115 - Fax By: /s/Christopher D. Leavins CHRISTOPHER D. LEAVINS
Texas Bar No. 24059205 cleavins@germer.com
ATTORNEY FOR
APPLICANT
NOTICE TO CREDITORS
Notice is hereby given that original Letters of Testamentary for the Estate of Rodnal Duhon, Deceased, were issued on July 21, 2026, in Cause No. 2026-0118-PR, pending in the County Court at Law of Orange County, Texas, to Jessica Nicole Mauboules.
All persons having claims against this Estate which is currently being administered are required to present them to the undersigned within the time and in the manner prescribed by law.
TO: Jessica Nicole Mauboules
Independent Executrix for the Estate of Rodnal Duhon, Deceased
c/o: Jennifer Jackson Morones
Jackson Morones P.L.L.C.
P.O. Box 2383
Silsbee, Texas 77656
DATED September 14, 2026.
By:
/s/ Jennifer Jackson Morones
Jennifer Jackson Morones
SBOT: 24046480
JACKSON MORONES PLLC
P.O. Box 2383
222 N. 5th Street
Silsbee, Texas 77656
Telephone: (409) 385-9800
Facsimile: (409) 385-9801
Email: jennifer.morones@jmlawtexas.com
ATTORNEY FOR INDEPENDENT EXECUTRIX, JESSICA NICOLE MAUBOULES
NOTICE TO CREDITORS
Notice is hereby given that original Letters Testamentary for the Estate of SHIRLEY V. STACEY, Deceased, were issued on September 15, 2026, in Cause No. 2026-0161-PR, pending in the County Court at Law, Orange County, Texas, to: ELIZABETH NASH.
All persons having claims against this Estate which is currently being administered are required to present them to the undersigned within the time and in the manner prescribed by law.
c/o: ELIZABETH NASH 2517 Black Oak Drive Orange, TX 77632
DATED on this 15th day of September, 2026.
/s/ Tommy Gunn
TOMMY GUNN
Attorney for ELIZABETH NASH
Texas Bar No.: 08623700 202 S. Border Street Orange, TX 77630 Telephone: (409) 882-9990 Facsimile: (409) 882-0613 Email: tommy@gunnlaw.org
NOTICE TO CREDITORS
Notice is hereby given that original Letters Testamentary for the Estate of RICHARD OWEN BORDELON, Deceased, were issued on September 15, 2026, in Cause No. 2026-0154-PR, pending in the County Court at Law, Orange County, Texas, to: SHIRLEY K. BORDELON.
All persons having claims against this Estate which is currently being administered are required to present them to the undersigned within the time and in the manner prescribed by law.
c/o: SHIRLEY K. BORDELON
1300 Dolley Drive
Orange, TX 77632
DATED on this 15th day of September, 2026.
/s/ Tommy Gunn
TOMMY GUNN
Attorney for SHIRLEY K. BORDELON
Texas Bar No.: 08623700 202 S. Border Street Orange, TX 77630 Telephone: (409) 882-9990 Facsimile: (409) 882-0613 Email: tommy@gunnlaw.org
NOTICE TO CREDITORS
Notice is hereby given that original Letters Testamentary for the Estate of BRENDA JOYCE LAWSON, Deceased, were issued on September 15, 2026, in Cause No. 2026-0150-PR, pending in the County Court at Law, Orange County, Texas, to: JAMES HALBERT LAWSON, JR.
All persons having claims against this Estate which is currently being administered are required to present them to the undersigned within the time and in the manner prescribed by law.
c/o: JAMES HALBERT LAWSON, JR.
16354 FM 105
Orange, TX 77630
DATED the 15th day of September, 2026.
/s/ Tommy Gunn
TOMMY GUNN
Attorney for JAMES HALBERT LAWSON, JR.
Texas Bar No.: 08623700 202 S. Border Street Orange, TX 77630 Telephone: (409) 882-9990 Facsimile: (409) 882-0613 Email: tommy@gunnlaw.org
Notice is hereby given in accordance with the provisions of the Texas Alcoholic Beverage Code that Kroozin FM 365 LLC dba Kroozin Truckstop has filed for a Wine and Malt Beverage On Premises Permit to be located at 17457 I 10, Beaumont, Jefferson County, Texas.
Manager- Salima Datoo
/
Everett Cormier, Sr., Constable Pct. 6
Jefferson County, state of Texas
By
Chief Deputy Constable, Lester Wilson
The Minimum Bid is the lesser of 1) the amount awarded in the judgment plus interest and costs or 2) the adjudged value. However, the Minimum Bid for a person owning an interest in the property or for a person who is a party to the suit (other than a taxing unit), is the aggregate amount of the judgments against the property plus all costs of suit and sale. ALL SALES SUBJECT TO CANCELLATION WITHOUT PRIOR NOTICE. THERE MAY BE ADDITIONAL TAXES DUE ON THE PROPERTY WHICH HAVE BEEN ASSESSED SINCE THE DATE OF THE JUDGMENT.
Note: Prior to the day of the sale, a bidder must request a Statement of No Delinquent Tax Owed from the Jefferson County Tax Office. This request for statement is available on the Jefferson County Tax Office website or available at the tax office. If you are purchasing property in the name of a company, you must provide a copy of the Assumed Name Certificate, which can be obtained from the Jefferson County Clerk’s office or website, or a Franchise Tax Account Status, with a list of the officers and directors, which may obtain from the Texas Comptroller’s Office Website. If you are not an officer or director of the company, you must also provide a letter on company letterhead signed by an officer or director, giving you authorization to bid on behalf of the company.
A bidder at the sale must be registered, at the time the sale begins, with the person conducting the sale. The bidder must submit the letter (Statement of No Delinquent Taxes Owed) to the person conducting the sale. Once the sale begins at 10:00 a.m., no one will be allowed to obtain a bidder number.