INVITATION TO BID
BID NO. PW0726-06
Sealed bids will be received online until 2:00 p.m. (CST), THURSDAY,
AUGUST 20, 2026, for furnishing all plans, administration,
superintendence, labor, services, materials, tools, equipment, supplies,
transportation, utilities, and all other items and facilities necessary therefore, as
provided in the
Contract Documents for the construction of:
CITY OF BEAUMONT
AVALON STREET AND
PEVITOT ROAD
DRAINAGE
IMPROVEMENTS
BID NO. PW0726-06
Bids will be opened and publicly read in the City Council Chambers at City Hall. The City reserves the right to reject any or all bids, or to accept any bid or combination of bids deemed advantageous to it.
Bidders must submit an original Bid Bond,
Cashier’s Check, Certified Check or irrevocable Letter of Credit issued by a bank
satisfactory to the Owner, payable without recourse to the order of the City of Beaumont in an amount not less than five (5) percent of the largest possible bid amount as a guaranty that the Bidder will enter into contract and execute bond and guaranty in the form provided within fourteen (14) calendar days after date of Notice of Award of the
contract. Bids without the
required financial
security deposit will not be considered.
A MANDATORY virtual Pre-bid Conference will be held at 2:00 P.M., on WEDNESDAY, AUGUST 12, 2026, on Microsoft Teams. Attendees may join by internet or phone call:
https://bit.ly/3TdtXB7
+1 903-405-2009
Passcode: 345 202 369#
Attendance at the Pre-bid meeting is a prerequisite to bidding. Prior to the
pre-bid conference,
interested bidders should obtain forms of
proposal, contract, bond, and
specifications. No one will be allowed to enter the pre-bid virtually or
in-person if arrival is later than 5 minutes after the
designated time. Calls for any technical
difficulties must be made prior to the meeting.
Bidding forms,
specifications and all
necessary information may be downloaded from the City’s e-bids platform at: https://beaumonttexas.ionwave.net/Login.aspx and on civcastusa.com. There is no cost to view the plans, and printing can be done through the websites. Sets of hard copies of bidding Documents will not be sold.
Bids must be submitted through the City’s e-bids platform at: https://beaumonttexas.ionwave.net/Login.aspx. Vendors must register to
submit a bid. Be advised, e-bids is the only option to submit bids to the City of Beaumont effective 8/1/23.
Please make sure to reference Bid
Number: PW0726-06
CITY OF BEAUMONT,
TEXAS, OWNER
By: Tina Broussard
City Clerk
NOTICE TO BIDDERS
REQUEST FOR
PROPOSAL (RFP)
810 Medical Office
Building Security
Improvements
Issuing Entity Baptist
Hospitals of Southeast Texas
Submission Due Date August 20, 2026
Sole Point of Contact Reggie Wasson,
Safety Officer, rwasson@bhset.net, 409-828-8112
Baptist Hospitals of
Southeast Texas is
requesting proposals from qualified vendors to
provide and install security improvements for the 810 Medical Office Building. The project includes
additions to video
surveillance, access
control, panic alarm
capability, electrical
infrastructure, and associated roof/parapet support work required for proper installation and commissioning.
PROJECT PURPOSE AND BACKGROUND
The 810 Medical Office Building assessment identified the IT data closets, entry points, hallways, and parking lot as areas vulnerable to potential threats including assault, theft, burglary, and other security incidents. The requested improvements are intended to increase monitoring, strengthen controlled access, support emergency notification, and improve overall security coverage for the facility.
BASE SCOPE OF WORK
Video Surveillance: furnish, install, configure, license, and commission interior and exterior IP camera surveillance equipment, including required server/NVR equipment, camera switching, cabling, UPS, monitor, and video analytics/software licensing as applicable.
Electrical Work: include power required for camera junction boxes on four parking lot poles, quad receptacles in two data rooms, and core drilling with sleeves in two data rooms.
Roof/Parapet Work: include wall-mount bracket installation at roof/parapet camera locations, liquid flashing over brackets, and pipe box work for electrical routing where required.
Project Closeout: include configuration, commissioning, testing, as-built documentation, training/turnover, and warranty/support information.
CONTRACTOR QUALIFICATION REQUIREMENTS
Respondents performing security system work shall hold all licenses required for the proposed scope, including a current Texas security license issued by the Texas Department of Public Safety where applicable.
Respondents performing electrical work shall hold all electrical licenses required by the State of Texas.
Respondents shall identify manufacturer certifications, dealer authorizations, and integration partner credentials
relevant to the proposed video surveillance, access control, panic alarm, and related systems.
Respondents shall be capable of coordinating work in an active healthcare/medical office environment and shall comply with all owner, hospital facility, state, local, and federal requirements applicable to the work.
Respondents shall provide labor rate sheets for all applicable skill sets, including standard, overtime, weekend,
holiday, travel, and material markup rates.
PROPOSAL SUBMISSION REQUIREMENTS
Narrative proposal describing the respondent’s approach to the full project scope.
Itemized pricing by major scope category: video surveillance, access control, panic buttons, electrical work,
roof/parapet support work, software/licensing, project management, and closeout/training.
Proposed equipment list including quantities, model numbers, licensing assumptions, substitutions, and exclusions.
Project schedule showing procurement, installation, configuration, commissioning, and turnover milestones.
Description of after-hours availability, response time, support model, warranty terms, and escalation contacts.
Copies of applicable licenses, certifications, insurance, bonding capacity if required, and any subcontractor
qualifications.
Hospital or healthcare project references completed within the last five years, if available.
List of assumptions, exclusions, owner responsibilities, and required site access conditions.
FEDERALLY FUNDED SELECTION CRITERIA
Evaluation Category
Integrated video surveillance, access control, and panic alarm proposal
Weight Requested Contents
35% Technical approach, equipment list, certifications, licensing, rate sheets, material markup, and commissioning plan.
Evaluation Category
Electrical and roof/parapet support proposal
Weight Requested Contents
25% Electrical licensing, power/core-drill scope, roof/parapet support methods, waterproofing approach, rate sheets, and bonding information if required.
Evaluation Category
Proposed completion time and support availability
Weight Requested Contents
20% Project timeline, procurement lead times, after-hours support availability, response times, and turnover plan.
Evaluation Category
Past performance in hospital or healthcare setting
Weight Requested Contents
15% Relevant healthcare, medical office, critical infrastructure, or occupied-facility projects completed within the last five years.
Evaluation Category
Past work experience with Baptist Hospitals of Southeast Texas
Weight Requested Contents
5% Prior work history, familiarity with owner standards, and demonstrated ability to coordinate with facility stakeholders.
GENERAL CONDITIONS
Failure to apprise oneself of hospital, facility, state, local, federal, licensing, code, safety, and grant-related requirements will not excuse any bidder from compliance with applicable requirements.
All work shall be coordinated with facility representatives to minimize disruption to occupied areas and maintain safe
access to patient, visitor, staff, and tenant spaces.
The owner reserves the right to reject any or all bids, waive informalities, request clarification, negotiate scope, and
request new bids for the whole or any portion of the work.
The owner may reject incomplete proposals, proposals that do not demonstrate required licensing or qualifications, and proposals that fail to address the requested scope and submission requirements.
This notice is intended as a bid solicitation summary. The final RFP package, drawings, site conditions, and owner-issued addenda shall govern the work
LEGAL NOTICE
Advertisement for Invitation for Bids
August 6, 2026
Notice is hereby given that sealed bids will be accepted by Jefferson County Drainage District No. 6 for
a (IFB 26-022/SC) Term Contract for Trash Removal Services for Jefferson County Drainage District No.
6. Specifications for this project may be obtained from the Jefferson County Drainage District No. 6
Webpage https://dd6.org/departments/purchasing/notices-for-bid/
Bids are to be sealed and addressed to Jefferson County Drainage District No. 6 and marked “Administrative Sealed Bid” with (IFB 26-022/SC) Term Contract for Trash Removal Services, for Jefferson County Drainage District No. 6” on the outside of the envelope. Bidders shall forward an original and two (2) copies of their bid to the address shown below. The District does not accept bids submitted electronically. Late bids will be rejected as non-responsive.
Administrative bids will be
publicly opened and read aloud in the Jefferson County Drainage District No. 6 boardroom at the time and date below. Bidders are invited to attend the bid opening.
BID NAME: Term Contract for Trash Removal Services
BID NUMBER: IFB 26-022/SC
DUE DATE/TIME: 2:00 PM, August 20, 2026
MAIL OR DELIVER TO: Jefferson County Drainage District No. 6
6550 Walden Rd.
Beaumont, Texas 77707
Any questions relating to these requirements should be directed to Shelby Clodfelter, Buyer/Contract Administrator II, at 409-842-1818 or sclodfelter@dd6.org.
Jefferson County Drainage District No. 6 reserves the right to accept or reject any or all bids, to waive technicalities and to take whatever action is in the best interest of the District.
All interested vendors are invited to submit a bid in accordance with the terms and conditions stated in
this bid.
RESPONDENTS ARE STRONGLY ENCOURAGED TO CAREFULLY READ THE ENTIRE INVITATION.
Karen K. Johnson, MBA, CTCD, CTCM Chief Business Officer Jefferson County Drainage District No. 6, Texas
LEGAL NOTICE
Advertisement for Request for Proposal
August 6, 2026
Notice is hereby given that sealed proposals will be accepted by Jefferson County Drainage District No.
6’s (District) Purchasing Department for RFP 26-026/SC, Five (5) -Year Update to the Jefferson County Drainage District No. 6 Hazard Mitigation Plan. Specifications for this proposal may be obtained
from the District’s website, https://dd6.org/departments/purchasing/notices-for-bid/.
Proposals are to be sealed and addressed to the Chief Business Officer with the proposal number and name marked on the outside of the envelope or box. Proposers shall forward an original and four (4) hard copies of their proposal to the address shown below. Late proposals will be rejected as non-responsive. Proposals will be publicly opened and only the firm name will be read aloud in the Jefferson
County Drainage District No. 6 Board Room at the time and date below. Proposals shall be opened in a
manner that avoids disclosure of the contents to competing Proposers and maintains the confidentiality of the proposals during negotiations. Proposals will be open for public inspection after the award of the contract, except for trade secrets and confidential information. Proposers are invited to attend the sealed proposal opening.
PROPOSAL NAME: Five (5) -Year Update to the Jefferson County Drainage District No. 6 Hazard Mitigation Plan
PROPOSAL NO: RFP 26-026/SC
DUE DATE/TIME: 2:00 PM CDT, August 27, 2026
MAIL OR DELIVER TO: Jefferson County Drainage District No. 6 Purchasing Department
6550 Walden Road
Beaumont, Texas 77707
Any questions relating to these requirements should be directed to Shelby Clodfelter, CTCD, Buyer/Contract Administrator II, in writing to sclodfelter@dd6.org. by August 24, 2026, by 1:00 PM, CST.
Jefferson County Drainage District No. 6 reserves the right to accept or reject any or all bids, to waive
technicalities and to take whatever action is in the best interest of the District.
All interested vendors are invited to submit a proposal in accordance with the terms and conditions stated in this bid. All contractors/subcontractors whose System for Award Management (SAM.gov) registration is not active or that are debarred, suspended or otherwise excluded from or ineligible for participation in federal assistance programs may not undertake any activity in part or in full under this project.
RESPONDENTS ARE STRONGLY ENCOURAGED TO CAREFULLY READ THE ENTIRE INVITATION.
Karen K. Johnson, MBA, CTCD, CTCM Chief Business Officer Jefferson County Drainage District No. 6, Texas
LEGAL NOTICE
Advertisement for
Invitation for Bids
August 6, 2026
Notice is hereby given that sealed bids will be accepted by the Jefferson County
Drainage District No. 6 Purchasing Department for: (IFB 26-024/SC) Term Contract for Heavy Materials. for Jefferson County Drainage District No. 6. Specifications for this
project may be obtained from the Jefferson County Drainage District No. 6 webpage,
https://dd6.org/departments/purchasing/notices-for-bid
Bids are to be sealed and addressed to the Purchasing Department with the bid number and name marked on the outside of the envelope. Bidders shall forward an original and
three (3) copies of their bid to the address shown below. Jefferson County Drainage District No. 6 does not accept bids submitted electronically. Late bids will be rejected as non-responsive. Bids will be publicly opened and read aloud in the Jefferson County Drainage District No. 6 Boardroom at the time and date below. Bidders are invited to attend the
sealed bid opening.
BID NAME: Term Contract Heavy Materials
BID NO: IFB 26-024/SC
DUE DATE: 2:00 PM, August 20, 2026
MAIL OR DELIVER TO: Jefferson County Drainage District No. 6
Purchasing Department
6550 Walden Rd.
Beaumont, Texas 77707
Any questions relating to these requirements should be directed to Shelby Clodfelter, Buyer/Contract Administrator II, at 409-842-1818 or sclodfelter@dd6.org.
Jefferson County Drainage District No. 6 reserves the right to accept or reject any or all bids, to waive technicalities and to take whatever action is in the best interest of the District.
All interested vendors are invited to submit a bid in accordance with the terms and conditions stated in this bid.
RESPONDENTS ARE STRONGLY ENCOURAGED TO CAREFULLY READ THE ENTIRE INVITATION.
Karen K. Johnson, MBA, CTCD, CTCM Chief Business Officer Jefferson County Drainage District No. 6, Texas
LEGAL NOTICE
Advertisement of
Invitation for
Qualifications
August 6, 2026
Notice is hereby given that sealed bids will be accepted by Jefferson County Drainage District No. 6 for (RFQ 26-019/KKJ)
Professional Construction Inspection and Materials Testing Services for the Corley Diversion Project. Specifications for this
project may be obtained from the Jefferson County Drainage District No. 6 webpage
https://dd6.org/departments/purchasing/notices-for-bid/.
This project will be federally funded by the U.S. Housing and Urban Development (HUD) Department through the Texas General Land Office (GLO) via contract #24-065-004-E161. Firms shall comply with regulations governing the CDBG
Regional Mitigation Program (Regulation 24 CFR 570). Applicable requirements include but are not limited to compliance with the Davis-Bacon and Related Acts, Fair Labor Standards, Equal Employment Opportunity, Affirmative Action, Section
3 of the HUD Act of 1968, and contracting with small, minority, and disadvantaged firms, as detailed in the project manual. In addition, the successful Firms must ensure that employees and applicants for employment are not discriminated against
because of race, color, religion, sex, sexual identity, gender identity, or national origin.
All interested firms shall obtain a “Request for Qualifications” packet from the Jefferson County Drainage District No. 6 web site at https://dd6.org/departments/purchasing/notices-for-bid/ or request a copy via email to kjohnson@dd6.org .
All responses shall be submitted with an original and three (3) copies of their qualifications to the address shown below. The District does not accept qualifications electronically. Late submittals will be rejected as non-responsive. Qualifications will be publicly opened and only the names of responding firms will be read aloud at the Jefferson County Drainage District No. 6 facilities at the time and date below. Firms are invited to attend the sealed opening.
All qualifications shall be submitted to the Purchasing Department in a sealed envelope marked:
Request NAME: Professional Construction Inspection and Materials Testing Services
Request NO: RFQ 26-019/ KKJ
DUE DATE/TIME: 2:00 PM, August 27, 2026
MAIL OR DELIVER TO: Jefferson County Drainage District No. 6
6550 Walden Rd.
Beaumont, Texas 77707
Any questions relating to these requirements should be directed to Karen K. Johnson, MBA, CTCD, CTCM Chief Business Officer, in writing to kjohnson@dd6.org. by Friday, August 21, 2026 by 1:00 PM, CST. Jefferson County Drainage District No. 6 reserves the right to accept or reject any or all bids, to waive technicalities and to take whatever action is in the best interest of the District.
All interested vendors are invited to submit a bid in accordance with the terms and conditions stated in this bid. All contractors/subcontractors whose System for Award Management (SAM.gov) registration is not active or that are debarred,
suspended or otherwise excluded from or ineligible for participation in federal assistance programs may not undertake any
activity in part or in full under this project.
Karen K. Johnson, MBA, CTCD, CTCM Chief Business Officer Jefferson County Drainage District No. 6, Texas
ADVERTISEMENT FOR BIDS
Sealed lump sum BIDS will be received by the Board of Commissioners of the Port of
Beaumont Navigation District of Jefferson County, Texas at the Port of Beaumont Administrative Office, 1225 Main Street, Beaumont, Texas 77701 until 2:00 p.m. local time, Beaumont, Texas on September 2, 2026 for the Port of Beaumont Terminal Connectivity & Improvement Project, at which time the BIDS will be opened publicly and read aloud. Bidders or interested parties can participate in hearing the bids read aloud via teleconference. Any BIDS
received after closing time will be returned unopened.
Each BID must be submitted in a sealed envelope, addressed to Mr. Brandon Bergeron, Director of Engineering, at the Port of Beaumont, P.O. Drawer 2297, Beaumont, Texas 77704. Each sealed envelope containing a BID must be plainly marked on the outside as BID for Port of Beaumont Terminal Connectivity & Improvement Project and the envelope should bear on the outside the name of the BIDDER, its address, and its contractor’s license number (if applicable). If forwarded by overnight or express mail, the sealed envelope containing the BID must be enclosed in another envelope addressed to Mr. Brandon Bergeron, Port of Beaumont, 1225 Main Street, Beaumont, Texas 77701. For purposes of express mail forms, the Port’s telephone number is (409) 835-5367. BIDS received electronically, or by telefacsimile, will not be accepted.
A pre-bid conference will be held at the Port of Beaumont Administrative Office, 1225 Main Street, Beaumont, Texas. The pre-bid conference will be held at 2:00 p.m. local time, Beaumont, Texas on August 18, 2026. ATTENDANCE AT THE PRE-BID CONFERENCE IS MANDATORY AND IS A PREREQUISITE TO A BIDDER BEING AWARDED THE BID.
TWIC Cards are required for all contractor and subcontractor employees that enter the Port of Beaumont. The contractor shall be responsible for obtaining these cards and the cost of these cards shall be included in the bid price. The Contractor will be responsible for obtaining training (performed by Port Authority Police) for their supervisors or designated employees to be certified as TWIC escorts to accompany any non-TWIC employees, subcontractors, vendors, etc as per 33 CFR 101.
Each BID must include a BID BOND (certified check, cashier’s check or BIDDER’S bond), equal to five percent (5%) of the amount of the BID. BID BONDS of unsuccessful BIDDERS will be returned.
Project includes, but is not necessarily limited to, the following items in accordance with the TECHNICAL SPECIFICATIONS and PROJECT DRAWINGS:
Mobilization/Demobilization
SWPPP & Site Preparation
Civil Demolition
Drainage Improvements
Subgrade Preparation
Full-Depth Repair of Pavement
Mill/Overlay Asphalt Pavement
Rail Improvements
Fencing & Gates
Signage and Striping
The BID Documents may be examined without charge at the Port of Beaumont’s address listed above during normal working hours.
The BID Documents will also be available at the Port’s website for download at the following website address: https://www.portofbeaumont.com/business-with-the-port/bids/.
In accordance with Texas State law, including Local Government Code Chapter 176, each BIDDER MUST COMPLETE AND SUBMIT WITH THEIR BID A COPY OF THE VENDOR’S CONFLICT OF INTEREST QUESTIONNAIRE CONTAINED IN EXHIBIT “O”.
The Port of Beaumont reserves the right to reject any or all BIDS and to waive
formalities in BIDDING. In case of ambiguity or lack of clearness in stating the price in any BID, the Port of Beaumont reserves the right to consider the most advantageous BID thereof, or reject the BID.
NOTICE OF PUBLIC SALE
Pursuant to Chapter 59, Texas Property Code, EZ Secure Storage will hold an online public auction of property being sold to satisfy a landlord’s lien. Sale to be held online at www.StorageTreasures.com. Facility location at 1715 Hwy 327 W, Silsbee, TX 77656. Bidding will open on 8/21/26 at 10 AM and conclude on 8/28/26 at 10 AM. Cleaning deposit required, payments must be made electronically, and items must be removed within 60 hours of auction end. Seller reserves the right to withdraw the property at any time before the sale. Unit items sold as-is to the highest bidder. Property includes the unit contents of the following tenants: Devon J Wise, Chaniqua Lattice Sells, Alicia Gaines, Renedia Anderson, Yasmine McSpadden. Contents include personal items, household goods, tools, toys, books, art, clothing, electronics and sporting goods.
NOTICE OF PUBLIC SALE
Pursuant to Chapter 59, Texas Property Code, EZ Secure Storage will hold an online public auction of property being sold to satisfy a landlord’s lien. Sale to be held online at www.StorageTreasures.com. Facility location at 5440 Old Dowlen Rd, Beaumont, TX 77706. Bidding will open on 8/21/26 at 10 AM and conclude on 8/28/26 at 10 AM. Cleaning deposit required, payments must be made electronically, and items must be removed within 60 hours of auction end. Seller reserves the right to withdraw the property at any time before the sale. Unit items sold as-is to the highest bidder. Property includes the unit contents of the following tenants: DJ Pena, Savannah Willis, Kierra Bronson, Jamie Howard, Courtney Goins, Vanity Mattox, Donna M Hankamer, Kimyunta Gilliam, LaToya Anderson. Contents include personal items, household goods, tools, furniture, toys, books, art, clothing, electronics and sporting goods.
CENTRAL MAXI
STORAGE
NOTICE OF PUBLIC SALE
Notice of Public Sale of Property to satisfy a landlord’s lien. Sale will be held at Central Maxi Storage 885 Ridgewood Dr. Port Neches, Texas 77651 on August 22nd,2026 at 1:15 PM. Clean up and card deposit of $45.00 is required. Seller reserves the right to withdraw the property at any time before the sale. Unit items will be sold for cash to the highest bidder. Property includes the contents of spaces of the following tenants:
Elizabeth Hernadez
Shenequa Jones
Barbara Wall
Mark Papania
Delia Minter
Van Thompson
Hermela Garnica
Orelia Normand
Ray Ramirez
Karla Galvan
Jairo Quinones
THE STATE OF TEXAS
NO. 25DCCV2342
lakeview loan
servicing, llc vs. yashica redo charles, et al.
CITATION BY
PUBLICATION-
2325 WILLOWGLEN DRIVE, BEAUMONT,
TEXAS 77707
136TH DISTRICT COURT
JEFFERSON COUNTY,
TEXAS
To: KENDALL
WENDELLIN CHARLES
DEFENDANT:
LOT 16, BLOCK 6, SOMEREST VILLAGE SECTION TWO, AN
ADDITION TO THE CITY OF BEAUMONT,
JEFFERSON COUNTY, TEXAS, ACCORDING TO THE MAP OR PLAT
RECORDED IN
VOLUME 14, PAGE 127, MAP RECORDS OF
JEFFERSON COUNTY, TEXAS
NOTICE: You have been sued. You may employ an attorney. If you or your
attorney do not file a
written answer with the clerk who issued this citation by 10:00 a.m. on the Monday next following the expiration of 42 days after the date this citation was issued, a
default judgment may be taken against you, the answer date being at or before 10 o’clock A.M. on Monday, August 31, 2026. In addition to filing a written answer with the clerk, you may be required to make initial disclosures to the
other parties of this suit. These disclosures generally must be made no later than 30 days after you file your answer with the clerk. Find out more at TexasLawHelp.org Said answer may be filed by mailing same to: District Clerk’s Office, 1085 Pearl St., Room 203, Beaumont, TX 77701, or by bringing it to the office. The case is presently pending before the 136th District Court District Court of Jefferson County sitting in Beaumont, Texas, and was filed on the 21st day of November, 2025. It bears cause number 25DCCV2342 and is styled:
Lakeview Loan Servicing, LLC vs. Yashica Redo Charles, et al.
The name and address of the attorney for plaintiff (or plaintiff if pro se) is:
WILLIAM A. MORPHIS
10405 STATE HIGHWAY 249 STE 249
HOUSTON, TX 77070
The nature of the demands of said plaintiff is shown by a true and correct copy of Plaintiff’s Signed Order Granting by Publication accompanying this citation and made a part thereof.
Issued under my hand and the seal of said court, at Beaumont, Texas, this the 14th day of July, 2026.
JAMIE SMITH,
DISTRICT CLERK
JEFFERSON COUNTY,
TEXAS
BY Erin Harper,
Erin Harper, Deputy
THE STATE OF TEXAS
NO. 26DCCV1241
Patricia C. Flores, et al vs. Alvin G.
Randolph iii, et al.
CITATION BY
PUBLICATION-
BERYL RANDOLPH
172ND DISTRICT COURT
JEFFERSON COUNTY,
TEXAS
To: GUSSIE HILL
DEFENDANT:
SEE ATTACHED
NOTICE: You have been sued. You may employ an attorney. If you or your attorney do not file a written answer with the clerk who issued this citation by 10:00 a.m. on the Monday next following the expiration of 42 days after the date this
citation was issued, a
default judgment may be taken against you, the
answer date being at or before 10 o’clock A.M. on Monday, August 24, 2026. In addition to filing a written
answer with the clerk, you may be required to make initial disclosures to the
other parties of this suit. These disclosures generally must be made no later than 30 days after you file your answer with the clerk. Find out more at TexasLawHelp.org Said answer may be filed by mailing same to: District Clerk’s Office, 1085 Pearl St., Room 203,
Beaumont, TX 77701, or by bringing it to the office. The case is presently pending before the 172nd District Court District Court of
Jefferson County sitting in Beaumont, Texas, and was filed on the 18th day of June, 2026. It bears cause number 26DCCV1241 and is styled:
Patricia C. Flores, et al, vs. Alvin G. Randolph III, et al.
The name and address of the attorney for plaintiff (or plaintiff if pro se) is:
MACK MITCHELL, JR.
6671 SOUTHWEST FWY., STE. 700
HOUSTON, TX 77074
The nature of the demands of said plaintiff is shown by a true and correct copy of Plaintiff’s Order-Signed accompanying this citation and made a part thereof.
Issued under my hand and the seal of said court, at Beaumont, Texas, this the 7th day of July, 2026.
JAMIE SMITH,
DISTRICT CLERK
JEFFERSON COUNTY,
TEXAS
BY Erin Harper,
Erin Harper, Deputy
THE STATE OF TEXAS
No. 26DCFM0396
IN THE MATTER OF THE MARRIAGE OF SHIAN LISA REGIS AND KEYANU JOSIAH SINGLETON
CITATION BY PUBLICATION
317TH DISTRICT COURT JEFFERSON COUNTY, TEXAS
To: KEYANU JOSIAH SINGLETON
AND TO ALL IT MAY CONCERN,
Keyanu Josiah singleton
RESPONDENT
NOTICE: You have been sued. You may employ an attorney. If you or your attorney do not file a written answer with the clerk who issued this citation by 10:00 a.m. on the Monday next following the expiration of 20 days after the date this citation was issued, a default judgment may be taken against you. The petition was filed on 30th day of March, 2026. Said answer may be filed by mailing same to: District Clerk’s Office, 1085 Pearl St., Room 203, Beaumont, TX 77701, or by bringing it to the office. The Petition of:
Shian Lisa Regis
was filed in the 317th District Court of Jefferson County, Texas, on the 30th day of March, 2026 against
KEYANU JOSIAH SINGLETON
RESPONDENT
numbered 26DCFM0396 and entitled ‘In the Interest of:
CARTIER ALLURE AMARI SINGLETON
TRE`SUR ITALY ROYALTY SINGLETON
The nature the suit is a request for ORIGINAL PETITION FOR DIVORCE
The date of birth of the child(ren) who is/are the subject of the suit is/are as follows:
CARTIER ALLURE AMARI SINGLETON 2/2/2022
TRE`SUR ITALY ROYALTY SINGLETON 2/20/2023
ISSUED and GIVEN under my hand and the seal of said court, at office, this 3rd day of August, 2026.
The court has the authority in this suit to enter any judgment or decree in the interest of the CHILD/CHILDREN will be binding upon you including the termination of the parent-child relationship, the determination of paternity and the appointment of a conservator with authority to consent to the adoption of the CHILD/CHILDREN.
JAMIE SMITH,
DISTRICT CLERK
JEFFERSON COUNTY, TX
BY Cielo Castillo, Deputy
Cielo Castillo, Deputy
NOTICE TO ALL PERSONS HAVING CLAIMS AGAINST THE ESTATE OF ROBERT W. SUNDERMEYER, DECEASED
Notice is hereby given that original Letters Testamentary for the ESTATE OF ROBERT W. SUNDERMEYER, DECEASED were issued on July 7, 2026 in Cause No. 26CCPR0692, pending in the County Court of Jefferson County, Texas, to Martha D. Sundermeyer.
The address of such Independent Executor is:
Martha D. Sundermeyer
2726 Ridgewood Lane
Nederland, TX 77627
All persons having claims against this Estate, which is currently being administered, are required to present them within the time and in the manner prescribed by law.
Dated this 4th day of August, 2026.
RANDY DREWETT, P.C.
6280 Delaware, Suite A
Beaumont, Texas 77706
(409) 833-4000
By: /s/ Randy Drewett
Randy Drewett, Attorney for Martha D. Sundermeyer,
Independent Executor
of the Estate
of Robert W. Sundermeyer,
Deceased
THE STATE OF TEXAS
No. 25DCCV1219
KW VENTURES, INC.
VS.
IVORY C. LOWE
CITATION BY
PUBLICATION –
IVORY C. LOWE
172ND DISTRICT COURT
JEFFERSON COUNTY,
TEXAS
To: Ivory C. Lowe
3043 KEYSTONE AVENUE
PORT ARTHUR, TEXAS 77640
DEFENDANT:
SEE ATTACHED
NOTICE: You have been sued. You may employ an attorney. If you or your attorney do not file a written answer with the clerk who issued this citation by 10:00 a.m. on the Monday next following the expiration of 42 days after the date this citation was issued, a default judgment may be taken against you, the answer date being at or before 10 o’clock A.M. on Monday, September 7, 2026. In addition to filing a written answer with the clerk, you may be required to make initial disclosures to the other parties of this suit. These disclosures generally must be made no later than 30 days after you file your answer with the clerk. Find out more at TexasLawHelp.org Said answer may be filed by mailing same to: District Clerk’s Office, 1085 Pearl, Room 203, Beaumont, TX 77701, or by bringing it to the office. The case is presently pending before the 172nd District Court District Court of Jefferson County sitting in Beaumont, Texas, and was filed on the 15th day of June 2026. It bears cause number 26DCCV1219 and is styled:
KW VENTURES, INC.
vs.
IVORY C. LOWE
The name and address of the attorney for plaintiff (or plaintiff if pro se) is:
ALEX WEATHERFORD
1400 BROADFIELD BOULEVARD STE 105
HOUSTON, TX. 77084
The nature of the demands of said plaintiff is shown by a true and correct copy of Plaintiff’s Brief accompanying this citation and made a part thereof.
Issued under my hand and the seal of said court, at Beaumont, Texas, this the 24th day of June, 2026.
JAMIE SMITH,
DISTRICT CLERK
JEFFERSON COUNTY,
TEXAS
BY Erin Harper,
Erin Harper, Deputy
THE STATE OF TEXAS
Cause No. 26DCFM0715
IN THE INTEREST OF S. J.
CITATION BY PUBLICATION
317th DISTRICT COURT
JEFFERSON COUNTY, TEXAS
To: JOSE LEONEL JARQUIN SANDIGO
AND TO ALL IT MAY CONCERN,
JOSE LEONEL JARQUIN SANDIGO, RESPONDENT
NOTICE: You have been sued. You may employ an attorney. If you or your attorney do not file a written answer with the clerk who issued this citation by 10:00 a.m. on the Monday next following the expiration of 20 days after the date this citation was issued, a default judgment may be taken against you. The petition was filed on 3rd day of June, 2026. Said answer may be filed by mailing same to: District Clerk’s Office, 1085 Pearl St., Rm. 203, Beaumont, TX 77701, or by bringing it to the office. The Petition of:
Nancy Sagrario Valle Narvaez
was filed in the 317th District Court of Jefferson County, Texas on the 3rd day of June 2026 against
JOSE LEONEL JARQUIN SANDIGO, RESPONDENT
numbered 26DCFM0715 and entitled ‘In the Interest of:
SAYANCY LORENA JARQUIN VALLE
TONY JOSE JARQUIN VALLE
The nature the suit is a request for ORIGINAL Petition IN SUIT AFFECTING PARENT-CHILD RELATIONSHIP.
The date of birth of the child(ren) who is/are the subject of the suit is as follows.
SAYANCY LORENA JARQUIN VALLE 11/16/2010
TONY JOSE JARQUIN VALLE 9/5/2008
ISSUED and GIVEN under my hand and the seal of said court at office, this the 5th day of June, 2026.
The court has the authority in this suit to enter any judgment or decree in the CHILD/CHILDREN will be binding upon you including the termination of the parent-child relationship, the determination of paternity and appointment of a conservator with authority to consent to the adoption of the CHILD/CHILDREN.
JAMIE SMITH,
DISTRICT CLERK
JEFFERSON COUNTY, TEXAS
BY Renee Garsee,
Renee Garsee, Deputy
No. 2026-0055-PR
ESTATE OF
LINDA RICHEY FAULK, DECEASED
§
IN THE COUNTY COURT OF
ORANGE, TEXAS
NOTICE
TO CREDITORS
Notice is hereby given that original Letters Testamentary for the Estate of Linda Richey Faulk, Deceased, were issued on June 9, 2026, in Cause No. 2026-0055-PR, pending In The County Court of Orange County, Texas, to: Michael Sherman Faulk.
c/o: Jeffrey T. Roebuck Attorney at Law
2372 Calder
Beaumont, Texas 77702
All persons having claims against this estate, which is currently being administered, must present them within the time and in the manner required by law.
Dated: July 29, 2026
ROEBUCK THOMAS ROEBUCK & ADAMS
2372 Calder
Beaumont, Texas 77702
Phone 409/892-8227
Fax 409/892-8318
By: Jeffrey T. Roebuck
Jeffrey T. Roebuck
Bar No. 24027812
jeff@roebuckthomas.com
THE STATE OF TEXAS
CITATION BY PUBLICATION
TO: UNKNOWN HEIRS OF
FILEMON BECERRA, DECEASED
DEFENDANT(S) GREETING:
YOU ARE HEREBY COMMANDED to appear before the Honorable Probate County Court of Jefferson County, Texas, at the Courthouse in the City of Beaumont, at or before 10 o’clock a.m. of the first Monday after the expiration of ten (10) days from the date of issuance thereof, same being Monday, 08/10/2026 then and there to answer the proceeding to declare heirship filed by Juana Becerra, Applicant, in said Court 07/28/2026 in Cause No. 26CCPR1045, styled,
IN THE ESTATE OF:
FILEMON BECERRA, DECEASED
A brief statement of the nature of the petition is as follows, to-wit:
DETERMINE THE HEIRS AND THEIR RESPECTIVE, SHARES & INTERESTS UNDER THE LAWS OF THIS STATE OR IN THE TRUST, AS APPLICABLE IN THE DECEDENT’S ESTATE
as is more fully shown by the petition on file in this cause.
The officer executing this process shall promptly execute the same according to law and make due return as the law directs. If this citation is not served within (90) days after day of issuance, it shall be returned unserved.
Issued and given under my hand and seal of said Court at Beaumont, Texas, on this 29th day of July, 2026.
Roxanne Acosta-Hellberg, County Clerk
Jefferson County, Texas
By Cecilia Garcia,
Cecilia Garcia,
Deputy Clerk
NO. 12698
ESTATE OF
JOHNNY LYNN FOUX,
DECEASED
§
IN THE COUNTY COURT OF
HARDIN COUNTY, TEXAS
PUBLISHED NOTICE
TO CREDITORS
Notice is hereby given that original Letters Testamentary for the Estate of JOHNNY LYNN FOUX, Deceased, were issued on August 3, 2026, in Docket No.12698 pending in the County Court of Hardin County, Texas, to: PAULINE ANN FOUX.
Claims may be presented in care of the attorney for the estate, addressed as follows:
PAULINE ANN FOUX
c/o William H. Yoes
THE YOES LAW FIRM, L.L.P.
P. O. Drawer 7584
Beaumont, Texas 77726-7584
All persons having claims against this estate, which is currently being administered, are required to present them within the time and in the manner prescribed by law.
DATED the 3rd day of August 2026.
Respectfully submitted,
THE YOES LAW FIRM, LLP 1855 Calder Avenue, Suite 200
Beaumont, Texas 77701
P. O. Box 7584
Beaumont, Texas 77726-7584
Tel: (409) 833-2352
Fax: (409) 838-5577
Email: why@yoeslawfirm.com
By: /s/ William H. Yoes
William H. Yoes
State Bar No. 22157000
ATTORNEY FOR THE
ESTATE OF JAMES DOUGLAS WHEELER
NO. 12697
ESTATE OF
JAMES DOUGLAS WHEELER,
DECEASED
§
IN THE COUNTY COURT OF
HARDIN COUNTY, TEXAS
PUBLISHED NOTICE
TO CREDITORS
Notice is hereby given that original Letters Testamentary for the Estate of JAMES DOUGLAS WHEELER, Deceased, were issued on August 3, 2026, in Docket No.12697 pending in the County Court of Hardin County, Texas, to: DEBORAH MAE BREEDEN WHEELER.
Claims may be presented in care of the attorney for the estate, addressed as follows:
DEBORAH MAE BREEDEN WHEELER
c/o William H. Yoes
THE YOES LAW FIRM, L.L.P.
P. O. Drawer 7584
Beaumont, Texas 77726-7584
All persons having claims against this estate, which is currently being administered, are required to present them within the time and in the manner prescribed by law.
DATED the 3rd day of August 2026.
Respectfully submitted,
THE YOES LAW FIRM, LLP 1855 Calder Avenue, Suite 200
Beaumont, Texas 77701
P. O. Box 7584
Beaumont, Texas 77726-7584
Tel: (409) 833-2352
Fax: (409) 838-5577
Email: why@yoeslawfirm.com
By: /s/ William H. Yoes
William H. Yoes
State Bar No. 22157000
ATTORNEY FOR THE
ESTATE OF JAMES DOUGLAS WHEELER
NOTICE TO CREDITORS
Notice is hereby given that original Letters Testamentary for the Estate of BENNIE LOUISE MILLER, Deceased, were issued on June 24, 2026, under Docket No. 26CCPR0003, pending in the County Court of Jefferson County, Texas, to GREGORY JAMISON HALL.
Claims may be presented in care of the attorney for the estate, addressed as follows:
GREGORY JAMISON HALL
Independent Executor,
Estate of BENNIE LOUISE MILLER, Deceased
c/o The Baldree Law Firm
1250 HWY 96 S
Silsbee, TX 77656
All persons having claims against this estate, which is currently being administered, are required to present them within the time and in the manner prescribed by law.
Dated July 30, 2026
The Baldree Law Firm
S/Daniel Baldree
Daniel Baldree
Attorney for the Estate
State Bar No. 24078183
713.446.1383-Telephone
409.419.1058-Facsimile
Baldreelawfirm@gmail.com
NOTICE TO CREDITORS
Notice is given that original Letters Testamentary for the Estate of David Brian Graham were issued on July 27, 2026, in Docket No. 26CCPR0919, pending in the County Court of Jefferson County, Texas, to Sheila Rae Graham. All persons having claims against the estate, which is presently being administered, are required to submit them, within the time and manner prescribed by law, and before the estate is closed, addressed as follows:
c/o Victoria Vaughan Laine
Attorney at Law
1045 Redwood Street
Kountze, TX 77625
Dated: July 29, 2026
/s/ Victoria Vaughan Laine
Victoria Vaughan Laine
Attorney for Executrix of the Estate of David Brian
Graham
NOTICE TO CREDITORS
NOTICE IS HEREBY GIVEN that original Letters Testamentary in the Estate
of Marguerite Sinegar aka Margurite Gibson Sinegar aka Marguerite Gibson Sinegar, Deceased, were issued on July 1, 2026, No. 26CCPR0691, In the County Court of Jefferson County, Texas, to:
Aline Marie Robinson
aka Aline Robinson
David Vann deCordova, Jr.
Law Office of David Vann deCordova, Jr.
1683 Lindbergh Drive
Beaumont, Texas 77707
All persons having claims against this Estate, which is currently being administered, are required to present them within the time and in the manner prescribed by law. Claims must be addressed in care of the representative at the above address.
DATED: July 31, 2026
David Vann Decordova, Jr.
Law Office of David Vann deCordova, Jr.
1683 Lindbergh Drive Beaumont, Texas 77707
Tel. No. 409.454-0240
Fax No. 409.291.8375
SBOT No. 05712550
LEGAL NOTICE
Notice is hereby given in accordance with the provisions of the Texas Alcoholic Beverage Code that NS Business Group, LLC DBA NS Grocery Store has filed for a
Wine and Malt Beverage Retail Dealer’s Off-Premise Permit to be issued for 3670 Detroit St, Beaumont, Jefferson County, Texas.
MD Mondal – Managing Member
Mohosin Akon – Managing Member
/
Everett Cormier, Sr., Constable Pct. 6
Jefferson County, state of Texas
By
Chief Deputy Constable, Lester Wilson
The Minimum Bid is the lesser of 1) the amount awarded in the judgment plus interest and costs or 2) the adjudged value. However, the Minimum Bid for a person owning an interest in the property or for a person who is a party to the suit (other than a taxing unit), is the aggregate amount of the judgments against the property plus all costs of suit and sale. ALL SALES SUBJECT TO CANCELLATION WITHOUT PRIOR NOTICE. THERE MAY BE ADDITIONAL TAXES DUE ON THE PROPERTY WHICH HAVE BEEN ASSESSED SINCE THE DATE OF THE JUDGMENT.
Note: Prior to the day of the sale, a bidder must request a Statement of No Delinquent Tax Owed from the Jefferson County Tax Office. This request for statement is available on the Jefferson County Tax Office website or available at the tax office. If you are purchasing property in the name of a company, you must provide a copy of the Assumed Name Certificate, which can be obtained from the Jefferson County Clerk’s office or website, or a Franchise Tax Account Status, with a list of the officers and directors, which may obtain from the Texas Comptroller’s Office Website. If you are not an officer or director of the company, you must also provide a letter on company letterhead signed by an officer or director, giving you authorization to bid on behalf of the company.
A bidder at the sale must be registered, at the time the sale begins, with the person conducting the sale. The bidder must submit the letter (Statement of No Delinquent Taxes Owed) to the person conducting the sale. Once the sale begins at 10:00 a.m., no one will be allowed to obtain a bidder number.